DAR File No. 39033

This rule was published in the January 15, 2015, issue (Vol. 2015, No. 2) of the Utah State Bulletin.


Administrative Services, Facilities Construction and Management

Rule R23-1

Procurement of Construction

Notice of Proposed Rule

(Repeal and Reenact)

DAR File No.: 39033
Filed: 12/24/2014 02:36:44 PM

RULE ANALYSIS

Purpose of the rule or reason for the change:

The purpose of this repeal and reenactment is to establish more specific rules on the general procurement provisions for the Division of Facilities Construction and Management.

Summary of the rule or change:

The previous rule reflected the requirements of the previous Utah Procurement Code which was enacted on or about 1981. The fundamental differences between the old rule and the new rule are that the new rule now reflects the current requirements listed in the 2014 Utah Procurement Code and implements the recent changes related to the 2014 Utah Procurement Code. Additionally, this rule is now more in line with the Division of Purchasing and General Services' rules.

State statutory or constitutional authorization for this rule:

  • Section 63G-6-208

Anticipated cost or savings to:

the state budget:

There are no anticipated costs or savings that are expected. The changes update the rule in order to implement and provide provisions related to the Utah Procurement Code, as well as to be more aligned with the Division of Purchasing and General Services rules.

local governments:

There are no anticipated costs or savings that are expected. The changes update the rule in order to implement and provide provisions related to the Utah Procurement Code, as well as to be more aligned with the Division of Purchasing and General Services rules.

small businesses:

There are no anticipated costs or savings that are expected. The changes update the rule in order to implement and provide provisions related to the Utah Procurement Code, as well as to be more aligned with the Division of Purchasing and General Services rules.

persons other than small businesses, businesses, or local governmental entities:

There are no anticipated costs or savings that are expected. The changes update the rule in order to implement and provide provisions related to the Utah Procurement Code, as well as to be more aligned with the Division of Purchasing and General Services rules.

Compliance costs for affected persons:

There are no compliance costs that are expected. The changes update the rule in order to implement and provide provisions related to the Utah Procurement Code, as well as to be more aligned with the Division of Purchasing and General Services rules.

Comments by the department head on the fiscal impact the rule may have on businesses:

There are no anticipated affects that the rule will have on businesses. The changes update the rule to implement and provide provisions related to the Utah Procurement Code, as well as to be more aligned with the Division of Purchasing and General Services rules.

Kimberly Hood, Executive Director

The full text of this rule may be inspected, during regular business hours, at the Division of Administrative Rules, or at:

Administrative Services
Facilities Construction and Management
Room 4110 STATE OFFICE BLDG
450 N STATE ST
SALT LAKE CITY, UT 84114-1201

Direct questions regarding this rule to:

  • Alan Bachman at the above address, by phone at 801-538-3105, by FAX at 801-538-3313, or by Internet E-mail at abachman@utah.gov
  • Cecilia Niederhauser at the above address, by phone at 801-538-3261, by FAX at 801-538-9694, or by Internet E-mail at cniederhauser@utah.gov
  • Nicole Alder at the above address, by phone at 801-538-3240, by FAX at , or by Internet E-mail at nicolealder@utah.gov

Interested persons may present their views on this rule by submitting written comments to the address above no later than 5:00 p.m. on:

02/17/2015

This rule may become effective on:

02/25/2015

Authorized by:

Bruce Whittington, Acting Director

RULE TEXT

R23. Administrative Services, Facilities Construction and Management.

[R23-1. Procurement of Construction.

R23-1-1. Purpose and Authority.

(1) In accordance with Subsection 63G-6-208, this rule establishes procedures for the procurement of construction by the Division.

(2) The statutory provisions governing the procurement of construction by the Division are contained in Section 63G-6-208 and Title 63A, Chapter 5.

 

R23-1-2. Definitions.

(1) Except as otherwise stated in this rule, terms used in this rule are defined in Section 63G-6-103.

(2) In addition:

(a) "Acceptable Bid Security" means a bid bond meeting the requirements of Subsection R23-1-40(4).

(b) "Board" means the State Building Board established pursuant to Section 63A-5-101.

(c) "Cost Data" means factual information concerning the cost of labor, material, overhead, and other cost elements which are expected to be incurred or which have been actually incurred by the contractor in performing the contract.

(d) "Director" means the Director of the Division, including, unless otherwise stated, his duly authorized designee.

(e) "Division" means the Division of Facilities Construction and Management established pursuant to Section 63A-5-201.

(f) "Established Market Price" means a current price, established in the usual and ordinary course of trade between buyers and sellers, which can be substantiated from sources independent of the manufacturer or supplier.

(g) "Price Data" means factual information concerning prices for supplies, services, or construction substantially identical to those being procured. Prices in this definition refer to offered or proposed selling prices and includes data relevant to both prime and subcontract prices.

(h) "Procuring Agencies" means, individually or collectively, the state, the Division, the owner and the using agency.

(i) "Products" means and includes materials, systems and equipment.

(j) "Proprietary Specification" means a specification which uses a brand name to describe the standard of quality, performance, and other characteristics needed to meet the procuring agencies' requirements or which is written in such a manner that restricts the procurement to one brand.

(k) "Public Notice" means the notice that is publicized pursuant to this rule to notify contractors of Invitations For Bids and Requests For Proposals.

(l) "Record" shall have the meaning defined in Section 63G-2-103 of the Government Records Access and Management Act (GRAMA).

(m) "Specification" means any description of the physical, functional or performance characteristics of a supply or construction item. It may include requirements for inspecting, testing, or preparing a supply or construction item for delivery or use.

(n) "State" means the State of Utah.

(o) "Subcontractor" means any person who has a contract with any person other than the procuring agency to perform any portion of the work on a project.

(p) "Using Agency" means any state agency or any political subdivision of the state which utilizes any services or construction procured under these rules.

(q) "Work" means the furnishing of labor or materials, or both.

 

R23-1-5. Competitive Sealed Bidding.

(1) Use. Competitive sealed bidding, which includes multi-step sealed bidding, shall be used for the procurement of construction if the design-bid-build method of construction contract management described in Subsection R23-1-45(5)(b) is used unless a determination is made by the Director in accordance with Subsection R23-1-15(1)(c) that the competitive sealed proposals procurement method should be used.

(2) Public Notice of Invitations For Bids.

(a) Public notice of Invitations For Bids shall be publicized electronically on the Internet; and may be publicized in any or all of the following as determined appropriate:

(i) In a newspaper having general circulation in the area in which the project is located;

(ii) In appropriate trade publications;

(iii) In a newspaper having general circulation in the state;

(iv) By any other method determined appropriate.

(b) A copy of the public notice shall be available for public inspection at the principal office of the Division in Salt Lake City, Utah.

(3) Content of the Public Notice. The public notice of Invitation For Bids shall include the following:

(a) The closing time and date for the submission of bids;

(b) The location to which bids are to be delivered;

(c) Directions for obtaining the bidding documents;

(d) A brief description of the project;

(e) Notice of any mandatory pre-bid meetings.

(4) Bidding Time. Bidding time is the period of time between the date of the first publication of the public notice and the final date and time set for the receipt of bids by the Division. Bidding time shall be set to provide bidders with reasonable time to prepare their bids and shall be not less than ten calendar days, unless a shorter time is deemed necessary for a particular project as determined in writing by the Director.

(5) Bidding Documents. The bidding documents for an Invitation For Bids:

(a) shall include a bid form having a space in which the bid prices shall be inserted and which the bidder shall sign and submit along with all other required documents and materials; and

(b) may include qualification requirements as appropriate.

(6) Addenda to the Bidding Documents.

(a) Addenda shall be distributed or otherwise made available to all entities known to have obtained the bidding documents.

(b) Addenda shall be distributed or otherwise made available within a reasonable time to allow all prospective bidders to consider them in preparing bids. If the time set for the final receipt of bids will not permit appropriate consideration, the bidding time shall be extended to allow proper consideration of the addenda.

(7) Pre-Opening Modification or Withdrawal of Bids.

(a) Bids may be modified or withdrawn by the bidder by written notice delivered to the location designated in the public notice where bids are to be delivered prior to the time set for the opening of bids.

(b) Bid security, if any, shall be returned to the bidder when withdrawal of the bid is permitted.

(c) All documents relating to the modification or withdrawal of bids shall be made a part of the appropriate project file.

(8) Late Bids, Late Withdrawals, and Late Modifications. Any bid, withdrawal of bid, or modification of bid received after the time and date set for the submission of bids at the location designated in the notice shall be deemed to be late and shall not be considered, unless it is the only bid received in which case it may be considered.

(9) Receipt, Opening, and Recording of Bids.

(a) Upon receipt, all bids and modifications shall be stored in a secure place until the time for bid opening.

(b) Bids and modifications shall be opened publicly, in the presence of one or more witnesses, at the time and place designated in the notice. The names of the bidders, the bid price, and other information deemed appropriate by the Director shall be read aloud or otherwise made available to the public. After the bid opening, the bids shall be tabulated or a bid abstract made. The opened bids shall be available for public inspection.

(10) Mistakes in Bids.

(a) If a mistake is attributable to an error in judgment, the bid may not be corrected. Bid correction or withdrawal by reason of an inadvertent, nonjudgmental mistake is permissible but only at the discretion of the Director and only to the extent it is not contrary to the interest of the procuring agencies or the fair treatment of other bidders.

(b) When it appears from a review of the bid that a mistake may have been made, the Director may request the bidder to confirm the bid in writing. Situations in which confirmation may be requested include obvious, apparent errors on the face of the bid or a bid substantially lower than the other bids submitted.

(c) This subsection sets forth procedures to be applied in three situations described below in which mistakes in bids are discovered after opening but before award.

(i) Minor formalities are matters which, in the discretion of the Director, are of form rather than substance evident from the bid document, or insignificant mistakes that can be waived or corrected without prejudice to other bidders and with respect to which, in the Director's discretion, the effect on price, quantity, quality, delivery, or contractual conditions is not or will not be significant. The Director, in his sole discretion, may waive minor formalities or allow the bidder to correct them depending on which is in the best interest of the procuring agencies. Examples include the failure of a bidder to:

(A) Sign the bid, but only if the unsigned bid is accompanied by other material indicating the bidder's intent to be bound;

(B) Acknowledge receipt of any addenda to the Invitation For Bids, but only if it is clear from the bid that the bidder received the addenda and intended to be bound by its terms; the addenda involved had a negligible effect on price, quantity, quality, or delivery; or the bidder acknowledged receipt of the addenda at the bid opening.

(ii) If the Director determines that the mistake and the intended bid are clearly evident on the face of the bid document, the bid shall be corrected to the intended bid and may not be withdrawn. Examples of mistakes that may be clearly evident on the face of the bid document are typographical errors, errors in extending unit prices, transposition errors, and arithmetical errors.

(iii) A bidder may be permitted to withdraw a low bid if the Director determines a mistake is clearly evident on the face of the bid document but the intended amount of the bid is not similarly evident, or the bidder submits to the Division proof which, in the Director's judgment, demonstrates that a mistake was made.

(d) No bidder shall be allowed to correct a mistake or withdraw a bid because of a mistake discovered after award of the contract; provided, that mistakes of the types described in this Subsection (10) may be corrected or the award of the contract canceled if the Director determines that correction or cancellation will not prejudice the interests of the procuring agencies or fair competition.

(e) The Director shall approve or deny in writing all requests to correct or withdraw a bid.

(11) Bid Evaluation and Award. Except as provided in the following sentence, the contract is to be awarded to the lowest responsible and responsive bidder whose bid meets the requirements and criteria set forth in the bidding documents and no bid shall be evaluated for any requirements or criteria that are not disclosed in the bidding documents. A reciprocal preference shall be granted to a resident contractor if the provisions of Section 63G-6-405 are met.

(12) Cancellation of Invitations For Bids; Rejection Of Bids in Whole or In Part.

(a) Although issuance of an Invitation For Bids does not compel award of a contract, the Division may cancel an Invitation For Bids or reject bids received in whole or in part only when the Director determines that it is in the best interests of the procuring agencies to do so.

(b) The reasons for cancellation or rejection shall be made a part of the project file and available for public inspection.

(c) Any determination of nonresponsibility of a bidder shall be made by the Director in writing and shall be based upon the criteria that the Director shall establish as relevant to this determination with respect to the particular project. An unreasonable failure of the bidder or to promptly supply information regarding responsibility may be grounds for a determination of nonresponsibility. Any bidder or determined to be nonresponsible shall be provided with a copy of the written determination within a reasonable time. The Board finds that it would impair governmental procurement proceedings by creating a disincentive for bidders to respond to inquiries of nonresponsibility. Therefore information furnished by a bidder or pursuant to any inquiry concerning responsibility shall be classified as a protected record pursuant to Section 63G-2-305 and may be disclosed only as provided for in Subsection R23-1-35.

(13) Tie Bids. Tie bids shall be resolved in accordance with Section 63G-6-426.

(14) Subcontractor Lists. For purposes of this Subsection (14), the definitions of Section 63A-5-208 shall be applicable. Within 24 hours after the bid opening time, not including Saturdays, Sundays and state holidays, the apparent lowest three bidders, as well as other bidders that desire to be considered, shall submit to the Division a list of their first-tier subcontractors that are in excess of the dollar amounts stated in Subsection 63-A-5-208(3)(a)(i)(A).

(a) The subcontractor list shall include the following:

(i) the type of work the subcontractor is to perform;

(ii) the subcontractor's name;

(iii) the subcontractor's bid amount;

(iv) the license number of the subcontractor issued by the Utah Division of Occupational and Professional Licensing, if such license is required under Utah law; and

(v) the impact that the selection of any alternate included in the solicitation would have on the information required by this Subsection (14).

(b) The contract documents for a specific project may require that additional information be provided regarding any contractor, subcontractor, or supplier.

(c) If pursuant to Subsection 63A-5-208(4)a, a bidder intends to perform the work of a subcontractor or obtain, at a later date, a bid from a qualified subcontractor, the bidder shall:

(i) comply with the requirements of Section 63A-5-208 and

(ii) clearly list himself on the subcontractor list form.

(d) Errors on the subcontractor list will not disqualify the bidder if the bidder can demonstrate that the error is a result of his reasonable reliance on information that was provided by the subcontractor and was used to meet the requirements of this section, and, provided that this does not result in an adjustment to the bidder's contract amount.

(e) Pursuant to Sections 63A-5-208 and 63G-2-305, information contained in the subcontractor list submitted to the Division shall be classified public except for the amount of subcontractor bids which shall be classified as protected until a contract has been awarded to the bidder at which time the subcontractor bid amounts shall be classified as public. During the time that the subcontractor bids are classified protected, they may only be made available to procurement and other officials involved with the review and approval of bids.

(15) Change of Listed Subcontractors. Subsequent to twenty-four hours after the bid opening, the contractor may change his listed subcontractors only after receiving written permission from the Director based on complying with all of the following:

(a) The contractor has established in writing that the change is in the best interest of the State and that the contractor establishes an appropriate reason for the change, which may include, but is not limited to, the following reasons:

(i) the original subcontractor has failed to perform, or is not qualified or capable of performing,

(ii) the subcontractor has requested in writing to be released;

(b) The circumstances related to the request for the change do not indicate any bad faith in the original listing of the subcontractors;

(c) Any requirement set forth by the Director to ensure that the process used to select a new subcontractor does not give rise to bid shopping;

(d) Any increase in the cost of the subject subcontractor work shall be borne by the contractor; and

(e) Any decrease in the cost of the subject subcontractor work shall result in a deductive change order being issued for the contract for such decreased amount.

 

R23-1-10. Multi-Step Sealed Bidding.

(1) Description. Multi-step sealed bidding is a two-phase process. In the first phase bidders submit unpriced technical offers to be evaluated. In the second phase, bids submitted by bidders whose technical offers are determined to be acceptable during the first phase are considered. It is designed to obtain the benefits of competitive sealed bidding by award of a contract to the lowest responsive, responsible bidder, and at the same time obtain the benefits of the competitive sealed proposals procedure through the solicitation of technical offers and the conduct of discussions to arrive at technical offers and terms acceptable to the Division and suitable for competitive pricing.

(2) Use. The multi-step sealed bidding method may be used when the Director deems it to the advantage of the state. Multi-step sealed bidding may be used when it is considered desirable:

(a) to invite and evaluate technical offers or statements of qualifications to determine their acceptability to fulfill the purchase description requirements;

(b) to conduct discussions for the purposes of facilitating understanding of the technical offer and purchase description requirements and, where appropriate, obtain supplemental information, permit amendments of technical offers, or amend the purchase description;

(c) to accomplish (a) or (b) prior to soliciting bids; and

(d) to award the contract to the lowest responsive and responsible bidder in accordance with the competitive sealed bidding procedures.

(3) Pre-Bid Conferences In Multi-Step Sealed Bidding. The Division may hold one or more pre-bid conferences prior to the submission of unpriced technical offers or at any time during the evaluation of the unpriced technical offers.

(4) Procedure for Phase One of Multi-Step Sealed Bidding.

(a) Public Notice. Multi-step sealed bidding shall be initiated by the issuance of a Public Notice in the form required by Subsections R23-1-5(2) and (3).

(b) Invitation for Bids. The multi-step Invitation for Bids shall state:

(i) that unpriced technical offers are requested;

(ii) when bids are to be submitted (if they are to be submitted at the same time as the unpriced technical offers, the bids shall be submitted in a separate sealed envelope);

(iii) that it is a multi-step sealed bid procurement, and bids will be considered only in the second phase and only from those bidders whose unpriced technical offers are found acceptable in the first phase;

(iv) the criteria to be used in the evaluation of the unpriced technical offers;

(v) that the Division, to the extent the Director finds necessary, may conduct oral or written discussions of the unpriced technical offers;

(vi) that the item being procured shall be furnished in accordance with the bidders technical offer as found to be finally acceptable and shall meet the requirements of the Invitation for Bids; and

(vii) that bidders may designate those portions of the unpriced technical offers which the bidder believes qualifies as a protected record as provided in Section R23-1-35. Such designated portions may be disclosed only as provided for in Section R23-1-35.

(c) Amendments to the Invitation for Bids. After receipt of unpriced technical offers, amendments to the Invitation for Bids shall be distributed only to bidders who submitted unpriced technical offers and they shall be allowed to submit new unpriced technical offers or to amend those submitted. If, in the opinion of the Director, a contemplated amendment will significantly change the nature of the procurement, the Invitation for Bids shall be canceled in accordance with Subsection R23-1-5(12) and a new Invitation for Bids may be issued.

(d) Receipt and Handling of Unpriced Technical Offers. After the date and time established for the receipt of unpriced technical offers, a register of bidders shall be open to public inspection. Prior to award, unpriced technical offers shall be shown only to those involved with the evaluation of the offers who shall adhere to the requirements of GRAMA and this rule. Except for those portions classified as protected under Section R23-1-35 or otherwise subject to non-disclosure under applicable law, unpriced technical offers shall be open to public inspection after award of the contract.

(e) Evaluation of Unpriced Technical Offers. The unpriced technical offers submitted by bidders shall be evaluated solely in accordance with the criteria set forth in the Invitation for Bids which may include an evaluation of the past performance of the bidder. The unpriced technical offers shall be categorized as acceptable or unacceptable. The Director shall record in writing the basis for finding an offer unacceptable and make it part of the procurement file.

(f) Discussion of Unpriced Technical Offers. Discussion of technical offers may be conducted with bidders who submit an acceptable technical offer. During the course of discussions, any information derived from one unpriced technical offer shall not be disclosed to any other bidder. Once discussions are begun, any bidder who has not been notified that its offer has been found unacceptable may submit supplemental information modifying or otherwise amending its technical offer until the closing date established by the Director. Submission may be made at the request of the Director or upon the bidder's own initiative.

(g) Notice of Unacceptable Unpriced Technical Offer. When the Director determines a bidder's unpriced technical offer to be unacceptable, he shall notify the bidder in writing. Such bidders shall not be afforded an additional opportunity to supplement technical offers.

(h) Confidentiality of Past Performance and Reference Information. Confidentiality of past performance and reference information shall be maintained in accordance with Subsection R23-1-15(10).

(5) Mistakes During Multi-Step Sealed Bidding. Mistakes may be corrected or bids may be withdrawn during phase one:

(a) before unpriced technical offers are considered;

(b) after any discussions have commenced under Subsection R23-1-10(4)(f); or

(c) when responding to any amendment of the Invitation for Bids. Otherwise mistakes may be corrected or withdrawal permitted in accordance with Subsection R23-1-5(10).

(6) Carrying Out Phase Two.

(a) Initiation. Upon the completion of phase one, the Director shall either:

(i) open bids submitted in phase one (if bids were required to be submitted) from bidders whose unpriced technical offers were found to be acceptable; provided, however, that the offers have remained unchanged, and the Invitation for Bids has not been amended subsequent to the submittal of bids; or

(ii) invite each acceptable bidder to submit a bid.

(b) Conduct. Phase two is to be conducted as any other competitive sealed bid procurement except:

(i) as specifically set forth in Section R23-1-10; and

(ii) no public notice is given of this invitation to submit.

 

R23-1-15. Competitive Sealed Proposals.

(1) Use.

(a) Construction Management. The competitive sealed proposals procurement method shall be used in the procurement of a construction manager under the construction manager/general contractor method of construction contract management described in Subsection R23-1-45(5)(d) due to the need to consider qualifications, past performance and services offered in addition to the cost of the services and because only a small portion of the ultimate construction cost is typically considered in this selection.

(b) Design-Build. In order to meet the requirements of Section 63G-6-703, competitive sealed proposals shall be used to procure design-build contracts.

(c) Design-Bid-Build. The competitive sealed proposals procurement method may be used for procuring a contractor under the design-bid-build method of construction contract management described in Subsection R23-1-45(5)(b) only after the Director makes a determination that it is in the best interests of the state to use the competitive sealed proposals method due to unique aspects of the project that warrant the consideration of qualifications, past performance, schedule or other factors in addition to cost.

(2) Documentation. The Director's determination made under Subsection R23-1-15(1)(c) shall be documented in writing and retained in the project file.

(3) Public Notice.

(a) Public notice of the Request for Proposals shall be publicized in the same manner provided for giving public notice of an Invitation for Bids, as provided in Subsection R23-1-5(2).

(b) The public notice shall include:

(i) a brief description of the project;

(ii) directions on how to obtain the Request for Proposal documents;

(iii) notice of any mandatory pre-proposal meetings; and

(iv) the closing date and time by which the first submittal of information is required;

(4) Proposal Preparation Time. Proposal preparation time is the period of time between the date of first publication of the public notice and the date and time set for the receipt of proposals by the Division. In each case, the proposal preparation time shall be set to provide offerors a reasonable time to prepare their proposals. The time between the first publication of the public notice and the earlier of the first required submittal of information or any mandatory pre-proposal meeting shall be not less than ten calendar days, unless a shorter time is deemed necessary for a particular procurement as determined, in writing, by the Director.

(5) Form of Proposal. The Request for Proposals may state the manner in which proposals are to be submitted, including any forms for that purpose.

(6) Addenda to Requests for Proposals. Addenda to the requests for proposals may be made in the same manner provided for addenda to the bidding documents in connection with Invitations for Bids set forth in Subsection R23-1-5(6) except that addenda may be issued to qualified offerors until the deadline for best and final offers.

(7) Modification or Withdrawal of Proposals.

(a) Proposals may be modified prior to the due dates established in the Request for Proposals.

(b) Proposals may be withdrawn until the notice of selection is issued.

(8) Late Proposals, and Late Modifications. Except for modifications allowed pursuant to negotiation, any proposal, or modification received at the location designated for receipt of proposals after the due dates established in the Request for Proposals shall be deemed to be late and shall not be considered unless there are no other offerors.

(9) Receipt and Registration of Proposals.

After the date established for the first receipt of proposals or other required information, a register of offerors shall be prepared and open to public inspection. Prior to award, proposals and modifications shall be shown only to procurement and other officials involved with the review and selection of proposals who shall adhere to the requirements of GRAMA and this rule.

(10) Confidentiality of Performance Evaluations and Reference Information. The Board finds that it is necessary to maintain the confidentiality of performance evaluations and reference information in order to avoid competitive injury and to encourage those persons providing the information to respond in an open and honest manner without fear of retribution. Accordingly, records containing performance evaluations and reference information are classified as protected records under the provisions of Section 63G-2-305 and shall be disclosed only to those persons involved with the performance evaluation, the contractor that the information addresses and procurement and other officials involved with the review and selection of proposals. The Division may, however, provide reference information to other governmental entities for use in their procurement activities and to other parties when requested by the contractor that is the subject of the information. Any other disclosure of such performance evaluations and reference information shall only be as required by applicable law.

(11) Evaluation of Proposals.

(a) The evaluation of proposals shall be conducted by an evaluation committee appointed by the Director that may include representatives of the Division, the Board, other procuring agencies, and contractors, architects, engineers, and others of the general public. Each member of the selection committee shall certify as to his lack of conflicts of interest.

(b) The Request for Proposals shall state all of the evaluation factors and the relative importance of price and other evaluation factors.

(c) The evaluation shall be based on the evaluation factors set forth in the request for proposals. Numerical rating systems may be used but are not required. Factors not specified in the request for proposals shall not be considered.

(d) Proposals may be initially classified as potentially acceptable or unacceptable. Offerors whose proposals are unacceptable shall be so notified by the Director in writing and they may not continue to participate in the selection process.

(e) This classification of proposals may occur at any time during the selection process once sufficient information is received to consider the potential acceptability of the offeror.

(f) The request for proposals may provide for a limited number of offerors who may be classified as potentially acceptable. In this case, the offerors considered to be most acceptable, up to the number of offerors allowed, shall be considered acceptable.

(12) Proposal Discussions with Individual Offerors.

(a) Unless only one proposal is received, proposal discussions with individual offerors, if held, shall be conducted with no less than the offerors submitting the two best proposals.

(b) Discussions are held to:

(i) Promote understanding of the procuring agency's requirements and the offerors' proposals; and

(ii) Facilitate arriving at a contract that will be most advantageous to the procuring agencies taking into consideration price and the other evaluation factors set forth in the request for proposals.

(c) Offerors shall be accorded fair and equal treatment with respect to any opportunity for discussions and revisions of proposals. In conducting discussions, there shall be no disclosure of any information derived from proposals submitted by competing offerors. Any oral clarification or change of a proposal shall be reduced to writing by the offeror.

(13) Best and Final Offers. If utilized, the Director shall establish a common time and date to submit best and final offers. Best and final offers shall be submitted only once unless the Director makes a written determination before each subsequent round of best and final offers demonstrating that another round is in the best interest of the procuring agencies and additional discussions will be conducted or the procuring agencies' requirements may be changed. Otherwise, no discussion of, or changes in, the best and final offers shall be allowed prior to award. Offerors shall also be informed that if they do not submit a notice of withdrawal or another best and final offer, their immediate previous offer will be construed as their best and final offer.

(14) Mistakes in Proposals.

(a) Mistakes discovered before the established due date. An offeror may correct mistakes discovered before the time and date established in the Request for Proposals for receipt of that information by withdrawing or correcting the proposal as provided in Subsection R23-1-15(7).

(b) Confirmation of proposal. When it appears from a review of the proposal before award that a mistake has been made, the offeror may be asked to confirm the proposal. Situations in which confirmation may be requested include obvious, apparent errors on the face of the proposal or a proposal amount that is substantially lower than the other proposals submitted. If the offeror alleges mistake, the proposal may be corrected or withdrawn as provided for in this section.

(c) Minor formalities. Minor formalities, unless otherwise corrected by an offeror as provided in this section, shall be treated as they are under Subsection R23-1-5(10)(c).

(d) Mistakes discovered after award. Offeror shall be bound to all terms, conditions and statements in offeror's proposal after award of the contract.

(15) Award.

(a) Award Documentation. A brief written justification statement shall be made showing the basis on which the award was found to be most advantageous to the state taking into consideration price and the other evaluation factors set forth in the Request for Proposals.

(b) One proposal received. If only one proposal is received in response to a Request for Proposals, the Director may, as he deems appropriate, make an award or, if time permits, resolicit for the purpose of obtaining additional competitive sealed proposals.

(16) Publicizing Awards.

(a) Notice. After the selection of the successful offeror(s), notice of award shall be available in the principal office of the Division in Salt Lake City, Utah and may be available on the Internet.

(b) Information Disclosed. The following shall be disclosed with the notice of award:

(i) the rankings of the proposals;

(ii) the names of the selection committee members;

(iii) the amount of each offeror's cost proposal;

(iv) the final scores used by the selection committee to make the selection, except that the names of the individual scorers shall not be associated with their individual scores; and

(v) the written justification statement supporting the selection.

(c) Information Classified as Protected. After due consideration and public input, the following has been determined by the Board to impair governmental procurement proceedings or give an unfair advantage to any person proposing to enter into a contract with the Division and shall be classified as protected records:

(i) the names of individual selection committee scorers in relation to their individual scores or rankings; and

(ii) non-public financial statements.

 

R23-1-17. Bids Over Budget.

(1) In the event all bids for a construction project exceed available funds as certified by the appropriate fiscal officer, and the low responsive and responsible bid does not exceed those funds by more than 5%, the Director may, where time or economic considerations preclude resolicitation of work of a reduced scope, negotiate an adjustment of the bid price, including changes in the bid requirements, with the low responsive and responsible bidder in order to bring the bid within the amount of available funds.

(2) As an alternative to the procedure authorized in Subsection (1), when all bids for a construction project exceed available funds as certified by the Director, and the Director finds that due to time or economic considerations the re-solicitation of a reduced scope of work would not be in the interest of the state, the Director may negotiate an adjustment in the bid price using one of the following methods:

(a) reducing the scope of work in specific subcontract areas and supervising the re-bid of those subcontracts by the low responsive and responsible bidder;

(b) negotiating with the low responsive and responsible bidder for a reduction in scope and cost with the value of those reductions validated in accordance with Section R23-1-50; or

(c) revising the contract documents and soliciting new bids only from bidders who submitted a responsive bid on the original solicitation. This re-solicitation may have a shorter bid response time than otherwise required.

(3) The use of one of the alternative procedures provided for in this subsection (2) must provide for the fair and equitable treatment of bidders.

(4) The Director's written determination, including a brief explanation of the basis for the decision shall be included in the contact file.

(5) This section does not restrict in any way, the right of the Director to use any emergency or sole source procurement provisions, or any other applicable provisions of State law or rule which may be used to award the construction project.

 

R23-1-20. Small Purchases.

(1) Procurements of $100,000 or Less.

(a) The Director may make procurements of construction estimated to cost $100,000 or less by soliciting at least two firms to submit written quotations. The award shall be made to the firm offering the lowest acceptable quotation.

(b) The names of the persons submitting quotations and the date and amount of each quotation shall be recorded and maintained as a public record by the Division.

(c) If the Director determines that other factors in addition to cost should be considered in a procurement of construction estimated to cost $100,000 or less, the Director shall solicit proposals from at least two firms. The award shall be made to the firm offering the best proposal as determined through application of the procedures provided for in Section R23-1-15 except that a public notice is not required and only invited firms may submit proposals.

(2) Procurements of $25,000 or Less. The Director may make small purchases of construction of $25,000 or less in any manner that the Director shall deem to be adequate and reasonable.

(3) Professional Services related to Construction. Small purchases for Architect or Engineer services may be procured as a small purchase in accordance with Rule R23-2-20. For other professional services related to construction, including cost estimators, project schedulers, building inspectors, code inspectors, special inspectors and testing entities; the Director may make small purchases of such professional services if the cost of such professional service is $100,000 or less in any manner that the Director shall deem to be adequate and reasonable.

(4) Division of Procurements. Procurements shall not be divided in order to qualify for the procedures outlined in this section.

 

R23-1-25. Sole Source Procurement.

(1) Conditions for Use of Sole Source Procurement.

The procedures concerning sole source procurement in this Section may be used if, in the discretion of the Director, a requirement is reasonably available only from a single source. Examples of circumstances which could also necessitate sole source procurement are:

(a) where the compatibility of product design, equipment, accessories, or replacement parts is the paramount consideration;

(b) where a sole supplier's item is needed for trial use or testing;

(c) procurement of public utility services;

(d) when it is a condition of a donation that will fund the full cost of the supply, material, equipment, service, or construction item.

(2) Written Determination. The determination as to whether a procurement shall be made as a sole source shall be made by the Director in writing and may cover more than one procurement. In cases of reasonable doubt, competition shall be solicited.

(3) Negotiation in Sole Source Procurement. The Director shall negotiate with the sole source vendor for considerations of price, delivery, and other terms.

 

R23-1-30. Emergency Procurements.

(1) Application. This section shall apply to every procurement of construction made under emergency conditions that will not permit other source selection methods to be used.

(2) Definition of Emergency Conditions. An emergency condition is a situation which creates a threat to public health, welfare, or safety such as may arise by reason of floods, epidemics, riots, natural disasters, wars, destruction of property, building or equipment failures, or any emergency proclaimed by governmental authorities.

(3) Scope of Emergency Procurements. Emergency procurements shall be limited to only those construction items necessary to meet the emergency.

(4) Authority to Make Emergency Procurements.

(a) The Division makes emergency procurements of construction when, in the Director's determination, an emergency condition exists or will exist and the need cannot be met through other procurement methods.

(b) The procurement process shall be considered unsuccessful when all bids or proposals received pursuant to an Invitation For Bids or Request For Proposals are nonresponsive, unreasonable, noncompetitive, or exceed available funds as certified by the appropriate fiscal officer, and time or other circumstances will not permit the delay required to resolicit competitive sealed bids or proposals. If emergency conditions exist after or are brought about by an unsuccessful procurement process, an emergency procurement may be made.

(5) Source Selection Methods. The source selection method used for emergency procurement shall be selected by the Director with a view to assuring that the required services of construction items are procured in time to meet the emergency. Given this constraint, as much competition as the Director determines to be practicable shall be obtained.

(6) Specifications. The Director may use any appropriate specifications without being subject to the requirements of Section R23-1-55.

(7) Required Construction Contract Clauses. The Director may modify or not use the construction contract clauses otherwise required by Section R23-1-60.

(8) Written Determination. The Director shall make a written determination stating the basis for each emergency procurement and for the selection of the particular source. This determination shall be included in the project file.

 

R23-1-35. Protected Records.

(1) General Classification. Records submitted to the Division in a procurement process are classified as public unless a different classification is determined in accordance with Title 63G, Chapter 2, U.C.A., Government Records Access and Management Act, hereinafter referred to as GRAMA.

(2) Protected Records. Records meeting the requirements of Section 63G-2-305 will be treated as protected records if the procedural requirements of GRAMA are met. Examples of protected records include the following:

(a) trade secrets, as defined in Section 13-24-2, if the requirements of Subsection R23-1-35(3) are met;

(b) commercial information or nonindividual financial information if the requirements of Subsection 63G-2-305(2) and Subsection R23-1-35(3) are met; and

(c) records the disclosure of which would impair governmental procurement proceedings or give an unfair advantage to any person proposing to enter into a contract with the Division, including, but not limited to, those records for which such a determination is made in this rule R23-1, Procurement of Construction, or Rule R23-2, Procurement of Architect-Engineer Services.

(3) Requests for Protected Status. Persons who believe that a submitted record, or portion thereof, should be protected under the classifications listed in Subsections R23-1-35(2)(a) and R23-1-35(2)(b) shall provide with the record a written claim of business confidentiality and a concise statement of reasons supporting the claim of business confidentiality. Such statements must address each portion of a document for which protected status is requested.

(4) Notification. A person who complies with this Section R23-1-35 shall be notified by the Division prior to the Division's public release of any information for which business confidentiality has been asserted.

(5) Disclosure of Records and Appeal. The records access determination and any further appeal of such determination shall be made in accordance with the provisions of Sections 63G-2-309 and 63G-2-401 et seq., GRAMA.

(6) Not Limit Rights. Nothing in this rule shall be construed to limit the right of the Division to protect a record from public disclosure where such protection is allowed by law.

 

R23-1-40. Acceptable Bid Security; Performance and Payment Bonds.

(1) Application. The requirements for bid security and bonds under this Rule R23-1-40 shall apply as follows:

(a) For the Division, the award of construction contracts where the face amount of the contract is $100,000 or more.

(b) For other state agencies that are required to use the same or similar documents as the Division for their construction contracts, the award of construction contracts where the face amount of the contract is $50,000 or more, unless the Division Director, in writing, approves a $100,000 or more requirement similarly to the Division, based on:

(i) The Division Director's finding that the agency has a selection process for such contracts that are under $100,000, that ensures a responsible, financially solvent contractor is selected; and

(ii) that the agency has the financial capability to absorb the potential responsibility that can occur due to the lack of the bid security and bonding requirements for the contract under $100,000.

(c) At any time the Division or any other state agency can require acceptable bid security as well as performance and payment bonds on contracts that are for amounts below the standard requirements set forth above in this Rule.

(2) Acceptable Bid Security.

(a) Invitations for Bids and Requests For Proposals shall require the submission of acceptable bid security in an amount equal to at least five percent of the bid, at the time the bid is submitted. If a contractor fails to accompany its bid with acceptable bid security, the bid shall be deemed nonresponsive, unless this failure is found to be nonsubstantial as hereinafter provided.

(b) If acceptable bid security is not furnished, the bid shall be rejected as nonresponsive, unless the failure to comply is determined by the Director to be nonsubstantial. Failure to submit an acceptable bid security may be deemed nonsubstantial if:

(i)(A) the bid security is submitted on a form other than the Division's required bid bond form and the bid security meets all other requirements including being issued by a surety meeting the requirements of Subsection (5); and

(B) the contractor provides acceptable bid security by the close of business of the next succeeding business day after the Division notified the contractor of the defective bid security; or

(ii) only one bid is received.

(3) Payment and Performance Bonds. Except as provided in Rule 23-1-40 (1) above, payment and performance bonds in the amount of 100% of the contract price are required for all contracts in excess of $50,000. These bonds shall cover the procuring agencies and be delivered by the contractor to the Division at the same time the contract is executed. If a contractor fails to deliver the required bonds, the contractor's bid shall be found nonresponsive and its bid security shall be forfeited.

(4) Forms of Bonds. Bid Bonds, Payment Bonds and Performance Bonds must be from sureties meeting the requirements of Subsection (5) and must be on the exact bond forms most recently adopted by the Board and on file with the Division.

(5) Surety firm requirements. All surety firms must be authorized to do business in the State of Utah and be listed in the U.S. Department of the Treasury Circular 570, Companies Holding Certificates of Authority as Acceptable Securities on Federal Bonds and as Acceptable Reinsuring Companies for an amount not less than the amount of the bond to be issued. A co-surety may be utilized to satisfy this requirement.

(6) Waiver. The Director may waive the bonding requirement if the Director finds, in writing, that bonds cannot be reasonably obtained for the work involved.

 

R23-1-45. Methods of Construction Contract Management.

(1) Application. This section contains provisions applicable to the selection of the appropriate type of construction contract management.

(2) Flexibility. The Director shall have sufficient flexibility in formulating the construction contract management method for a particular project to fulfill the needs of the procuring agencies. In each instance consideration commensurate with the project's size and importance should be given to all the appropriate and effective means of obtaining both the design and construction of the project. The methods for achieving the purposes set forth in this rule are not to be construed as an exclusive list.

(3) Selecting the Method of Construction Contracting. In selecting the construction contracting method, the Director shall consider the results achieved on similar projects in the past, the methods used, and other appropriate and effective methods and how they might be adapted or combined to fulfill the needs of the procuring agencies. The use of the design-bid-build method is an appropriate contracting method for the majority of construction contracts entered into by the Division with a cost equal to or less than $1,500,000 and the construction manager/general contractor method is an appropriate contracting method for the majority of construction contracts entered into by the Division with a cost greater than $1,500,000. The Director shall include a statement in the project file setting forth the basis for using any construction contracting method other than those suggested in the preceding sentence.

(4) Criteria for Selecting Construction Contracting Methods. Before choosing the construction contracting method to use, the Director shall consider the factors outlined in Subsection 63G-6-501(1)(c).

(5) General Descriptions.

(a) Application of Descriptions. The following descriptions are provided for the more common contracting methods. The methods described are not all mutually exclusive and may be combined on a project. These descriptions are not intended to be fixed for all construction projects of the State. In each project, these descriptions may be adapted to fit the circumstances of that project.

(b) Design-Bid-Build. The design-bid-build method is typified by one business, acting as a general contractor, contracting with the state to complete a construction project in accordance with drawings and specifications provided by the state within a defined time period. Generally the drawings and specifications are prepared by an architectural or engineering firm under contract with the state. Further, while the general contractor may take responsibility for successful completion of the project, much of the work may be performed by specialty contractors with whom the prime contractor has entered into subcontracts.

(c) Design-Build. In a design-build project, a business contracts directly with the Division to meet requirements described in a set of performance specifications. The design-build contractor is responsible for both design and construction. This method can include instances where the design-build contractor supplies the site as part of the package.

(d) Construction Manager/General Contractor. A construction manager/general contractor is a firm experienced in construction that provides professional services to evaluate and to implement drawings and specifications as they affect time, cost, and quality of construction and the ability to coordinate the construction of the project, including the administration of change orders. The Division may contract with the construction manager/general contractor early in a project to assist in the development of a cost effective design. The construction manager/general contractor will generally become the general contractor for the project and procure subcontract work at a later date. The procurement of a construction manager/general contractor may be based, among other criteria, on proposals for a management fee which is either a lump sum or a percentage of construction costs with a guaranteed maximum cost. If the design is sufficiently developed prior to the selection of a construction manager/general contractor, the procurement may be based on proposals for a lump sum or guaranteed maximum cost for the construction of the project. The contract with the construction manager/general contractor may provide for a sharing of any savings which are achieved below the guaranteed maximum cost. When entering into any subcontract that was not specifically included in the Construction Manager/General Contractor's cost proposal submitted in the original procurement of the Construction Manager/General Contractor's services, the Construction Manager/General Contractor shall procure that subcontractor by using one of the source selection methods provided for in Sections 63G-6-401 through 63G-6-426, in a similar manner as if the subcontract work was procured directly by the Division.

 

R23-1-50. Cost or Pricing Data and Analysis; Audits.

(1) Applicability. Cost or pricing data shall be required when negotiating contracts and adjustments to contracts if:

(a) adequate price competition is not obtained as provided in Subsection (2); and

(b) the amounts set forth in Subsection (3) are exceeded.

(2) Adequate Price Competition. Adequate price competition is achieved for portions of contracts or entire contracts when one of the following is met:

(a) When a contract is awarded based on competitive sealed bidding;

(b) When a contractor is selected from competitive sealed proposals and cost was one of the selection criteria;

(c) For that portion of a contract that is for a lump sum amount or a fixed percentage of other costs when the contractor was selected from competitive sealed proposals and the cost of the lump sum or percentage amount was one of the selection criteria;

(d) For that portion of a contract for which adequate price competition was not otherwise obtained when competitive bids were obtained and documented by either the Division or the contractor;

(e) When costs are based upon established catalogue or market prices;

(f) When costs are set by law or rule;

(g) When the Director makes a written determination that other circumstances have resulted in adequate price competition.

(3) Amounts. This section does not apply to:

(a) Contracts or portions of contracts costing less than $100,000, and

(b) Change orders and other price adjustments of less than $25,000.

(4) Other Applications. The Director may apply the requirements of this section to any contract or price adjustment when he determines that it would be in the best interest of the state.

(5) Submission of Cost or Pricing Data and Certification. When cost or pricing data is required, the data shall be submitted prior to beginning price negotiation. The offeror or contractor shall keep the data current throughout the negotiations certify as soon as practicable after agreement is reached on price that the cost or pricing data submitted are accurate, complete, and current as of a mutually determined date.

(6) Refusal to Submit. If the offeror refuses to submit the required data, the Director shall determine in writing whether to disqualify the noncomplying offeror, to defer award pending further investigation, or to enter into the contract. If a contractor refuses to submit the required data to support a price adjustment, the Director shall determine in writing whether to further investigate the price adjustment, to not allow any price adjustment, or to set the amount of the price adjustment.

(7) Defective Cost or Pricing Data. If certified cost or pricing data are subsequently found to have been inaccurate, incomplete, or noncurrent as of the date stated in the certificate, the Division shall be entitled to an adjustment of the contract price to exclude any significant sum, including profit or fee, to the extent the contract sum was increased because of the defective data. It is assumed that overstated cost or pricing data increased the contract price in the amount of the defect plus related overhead and profit or fee; therefore, unless there is a clear indication that the defective data were not used or relied upon, the price should be reduced by this amount. In establishing that the defective data caused an increase in the contract price, the Director shall not be required to reconstruct the negotiation by speculating as to what would have been the mental attitudes of the negotiating parties if the correct data had been submitted at the time of agreement on price.

(8) Audit. The Director may, at his discretion, and at reasonable times and places, audit or cause to be audited the books and information of a contractor, prospective contractor, subcontractor, or prospective subcontractor which are related to the cost or pricing data submitted.

(9) Retention of Books and Information. Any contractor who receives a contract or price adjustment for which cost or pricing data is required shall maintain all books and information that relate to the cost or pricing data for three years from the date of final payment under the contract. This requirement shall also extend to any subcontractors of the contractor.

 

R23-1-55. Specifications.

(1) General Provisions.

(a) Purpose. The purpose of a specification is to serve as a basis for obtaining a supply or construction item adequate and suitable for the procuring agencies' needs and the requirements of the project, in a cost-effective manner, taking into account, the costs of ownership and operation as well as initial acquisition costs. Specifications shall permit maximum practicable competition consistent with this purpose. Specifications shall be drafted with the objective of clearly describing the procuring agencies' requirements.

(b) Preference for Commercially Available Products. Recognized, commercially-available products shall be procured wherever practicable. In developing specifications, accepted commercial standards shall be used and unique products shall be avoided, to the extent practicable.

(c) Nonrestrictiveness Requirements. All specifications shall be written in such a manner as to describe the requirements to be met, without having the effect of exclusively requiring a proprietary supply, or construction item, or procurement from a sole source, unless no other manner of description will suffice. In that event, a written determination shall be made that it is not practicable to use a less restrictive specification.

(2) Director's Responsibilities.

(a) The Director is responsible for the preparation of all specifications.

(b) The Division may enter into contracts with others to prepare construction specifications when there will not be a substantial conflict of interest. The Director shall retain the authority to approve all specifications.

(c) Whenever specifications are prepared by persons other than Division personnel, the contract for the preparation of specifications shall require the specification writer to adhere to the requirements of this section.

(3) Types of Specifications. The Director may use any method of specifying construction items which he considers to be in the best interest of the state including the following:

(a) By a performance specification stating the results to be achieved with the contractor choosing the means.

(b) By a prescriptive specification describing a means for achieving desired, but normally unstated, ends. Prescriptive specifications include the following:

(i) Descriptive specifications, providing a detailed written description of the required properties of a product and the workmanship required to fabricate, erect and install without using trade names; or

(ii) Proprietary specifications, identifying the desired product by using manufacturers, brand names, model or type designation or important characteristics. This is further divided into two classes:

(A) Sole Source, where a rigid standard is specified and there are no allowed substitutions due to the nature of the conditions to be met. This may only be used when very restrictive standards are necessary and there is only one proprietary product known that will meet the rigid standards needed. A sole source proprietary specification must be approved by the Director.

(B) Or Equal, which allows substitutions if properly approved.

(c) By a reference standard specification where documents or publications are incorporated by reference as though included in their entirety.

(d) By a nonrestrictive specification which may describe elements of prescriptive or performance specifications, or both, in order to describe the end result, thereby giving the contractor latitude in methods, materials, delivery, conditions, cost or other characteristics or considerations to be satisfied.

(4) Procedures for the Development of Specifications.

(a) Specifications may designate alternate supplies or construction items where two or more design, functional, or proprietary performance criteria will satisfactorily meet the procuring agencies' requirements.

(b) The specification shall contain a nontechnical section to include any solicitation or contract term or condition such as a requirement for the time and place of bid opening, time of delivery, payment, liquidated damages, and similar contract matters.

(c) Use of Proprietary Specifications.

(i) The Director shall seek to designate three brands as a standard reference and shall state that substantially equivalent products to those designated will be considered for award, with particular conditions of approval being described in the specification.

(ii) Unless the Director determines that the essential characteristics of the brand names included in the proprietary specifications are commonly known in the industry or trade, proprietary specifications shall include a description of the particular design, functional, or performance characteristics which are required.

(iii) Where a proprietary specification is used in a solicitation, the solicitation shall contain explanatory language that the use of a brand name is for the purpose of describing the standard of quality, performance, and characteristics desired and is not intended to limit or restrict competition.

(iv) The Division shall solicit sources to achieve whatever degree of competition is practicable. If only one source can supply the requirement, the procurement shall be made in accordance with Section R23-1-25.

 

R23-1-60. Construction Contract Clauses.

(1) Required Contract Clauses. Pursuant to Section 63G-6-601, the document entitled "Required Construction Contract Clauses", Dated May 25, 2005, and on file with the Division, is hereby incorporated by reference. Except as provided in Subsections R23-1-30(7) and R23-1-60(2), the Division shall include these clauses in all construction contracts.

(2) Revisions to Contract Clauses. The clauses required by this section may be modified for use in any particular contract when, pursuant to Subsection 63G-6-601(5), the Director makes a written determination describing the circumstances justifying the variation or variations. Notice of any material variations from the contract clauses required by this section shall be included in any invitation for bids or request for proposals. Examples of changes that are not material variations include, but are not limited to, the following: grammatical corrections; corrections made that resolve conflicts in favor of the intent of the document as a whole; and changes that reflect State law or rule and applicable court case law.]

R23-1. Procurement Rules with Numbering Related to the Procurement Code.

R23-1-101. Scope of the Rules and Compliance by Using Agencies.

(1) Rule R23-1 applies to procurements by the Division of Facilities Construction and Management. This includes the procurement of construction, architects, engineers, design services and all other professional services and procurements related to design or construction by the Division of Facilities Construction and Management as well as other procurement items within the rule authorization of the Division of Facilities Construction and Management. Using Agencies are required to comply with these rules to extent required by the Utah Code.

(2) The statutory provisions governing the procurement referred to in R23-1-101(1) above are provided in the Utah Procurement Code, Title 63G, Chapter 6a of the Utah Code as well as Title 63A, Chapter 5 of the Utah Code.

 

R23-1-102. Definitions.

Terms used in this R23-1 are defined in Sections 63G-6a-103 and 104 of the Utah Procurement Code. In addition:

(1) "Actual Costs" means direct and indirect costs which have been incurred for services rendered, supplies delivered, or construction built, as distinguished from allowable costs.

(2) "Adequate Price" Competition means:

(a) when a minimum of two competitive bids, proposals, or quotes are received from responsive bidders or offerors.

(3) "Acquiring Agency" is a conducting procurement unit subject to Section 63F-1-205 acquiring new technology or technology as therein defined.

(4) "Bid Bond" is an insurance agreement, accompanied by a monetary commitment, by which a third party (the Surety) accepts liability and guarantees that the bidder will not withdraw the bid. The bidder will furnish bonds in the required amount and if the contract is awarded to the bonded bidder, the bidder will accept the contract as bid, or else the surety will pay a specific amount.

(5) "Bid Rigging" means agreement among potential competitors to manipulate the competitive bidding process, for example, by agreeing not to bid, to bid a specific price, to rotate bidding, or to give kickbacks.

(6) "Bid Security" means the deposit of cash, certified check, cashier's check, bank draft, money order, or bid bond submitted with a bid and serving to guarantee to the owner that the bidder, if awarded the contract, will execute such contract in accordance with the bidding requirements and the contract documents.

(7) "Board" means the State Building Board established pursuant to Section 63A-5-101.

(8) "Brand Name or Equal Specification" means a specification which uses a brand name specification to describe the standard of quality, performance, and other characteristics being solicited, and which invites the submission of equivalent products.

(9) "Brand Name Specification" means a specification identifying one or more products by manufacturer name, product name, unique product identification number, product description, SKU or catalogue number.

(10) "Collusion" means when two or more persons act together to achieve a fraudulent or unlawful act. Collusion inhibits free and open competition in violation of law.

(11) "Cost Analysis" means the evaluation of cost data for the purpose of arriving at estimates of costs to be incurred, prices to be paid, costs to be reimbursed, or costs actually incurred.

(12) "Cost Data" means factual information concerning the cost of labor, material, overhead, and other cost elements which are expected to be incurred or which have been actually incurred by the contractor in performing the contract.

(13) "Cronyism" is an anticompetitive practice that may violate federal and state antitrust and procurement laws. Cronyism in government contracting is a form of favoritism where contracts are awarded on the basis of friendships, associations or political connections instead of fair and open competition.

(14) "Director" means the Director of the Division, including, unless otherwise stated, the Director's duly authorized designee.

(15) "Division" means the Division of Facilities Construction and Management established pursuant to Section 63A-5-201.

(16) "Mandatory Requirement" means a condition set out in the specifications/statement of work that must be met without exception.

(17) "Minor Irregularity" is a variation from the solicitation that does not affect the price of the bid, offer, or contract or does not give a bidder/offeror an advantage or benefit not shared by other bidders/offerors, or does not adversely impact the interests of the procurement unit.

(18) "New Technology" means any invention, discovery, improvement, or innovation, that was not available to the acquiring agency on the effective date of the contract, whether or not patentable, including, but not limited to, new processes, emerging technology, machines, and improvements to, or new applications of, existing processes, machines, manufactures and software. Also included are new computer programs, and improvements to, or new applications of, existing computer programs, whether or not copyrightable and any new process, machine, including software, and improvements to, or new applications of, existing processes, machines, manufactures and software.

(19) "Participating Addendum" means an agreement issued in conjunction with a Cooperative Contract that authorizes a public entity to use the Cooperative Contract.

(20) "Payment Bond" is a bond that guarantees payment for labor and materials expended on the contract.

(21) "Price Analysis" means the evaluation of price data without analysis of the separate cost components and profit.

(22) "Price Data" means factual information concerning prices for procurement items.

(23) Record" shall have the meaning defined in Section 63G-2-103 of the Government Records Access and Management Act (GRAMA).

(24) "Section and Subsection" refers to the Utah Code.

(25) "Solicitations," in addition to the definition in 63G-6a -103 (48) also includes all documents, whether attached or incorporated by reference to the solicitation.

(26) "Surety bond" (performance bond) means a promise to pay one the oblige (owner) a certain amount if the principal (contractor) fails to meet some obligation, such as fulfilling the terms of a contract. The surety bond protects the oblige (owner) against losses resulting from the principal's failure to meet the obligation. In the event that the obligations are not met, the oblige (owner), will recover its losses via the bond.

(27) "Technology" means any type of technology defined in Section 63F-1-102(8).

(28) "Using Agency" means any state agency or any political subdivision of the state which utilizes the services procured under this Rule 23-1.

 

R23-1-103. Division is Issuing and Conducting Procurement Unit.

The Division is both the issuing and conducting procurement unit for procurements under this Rule R23-1.

 

R23-1-201. Director Appoint to Policy Board, Building Board Rules Authority.

(1) The Director shall appoint a representative to serve on the Utah State Procurement Policy Board.

(2) In accordance with Section 63G-6a-204(2), the Board rules governing procurement of construction, architect-engineer services, and leases apply to the procurement of construction, architect-engineer services, and leases of real property by the Division.

 

R23-1-301. Relationship with the Division of Purchasing and General Services.

(1) The Division recognizes the provisions of Part 3 of the Utah Procurement Code regarding the Chief Procurement Officer. The Division may participate as needed or required with trainings provided by the Division of Purchasing and General Services.

(2) The Director's responsibilities are provided in Title 63a, Chapter 5 of the Utah Code.

 

R23-1-401. Prequalification of Potential Vendors.

General procurement provisions, including prequalification of potential vendors, approved vendor lists, and small purchases shall be conducted in accordance with the requirements set forth in Sections 63G-6a-402 through 408. All definitions in the Utah Procurement Code shall apply to this Rule R23-1-4-4 unless otherwise specified in Rule 23-1. This Rule R23-4 provides additional requirements and procedures and must be used in conjunction with the Procurement Code.

 

R23-1-402. Thresholds for Approved Vendor Lists.

(1) Public entities may establish approved vendor lists in accordance with the requirements of Sections 63G-6a-403 and 63G-6a-404.

(a) Contracts or purchases from an approved vendor list may not exceed the following thresholds:

(i) Construction Projects: $2,500,000 per contract, for direct construction costs, including design and allowable furniture or equipment costs, awarded using an invitation for bids or a request for proposals;

(ii) Professional and General Services, including architectural and engineering services: $100,000; and

(b) Thresholds for other approved vendor lists may be established by the Director.

 

R23-1-403. Specifications.

(1) Solicitation documents shall include specifications for the procurement item(s).

(2) Specifications shall be drafted with the objective of clearly describing the Division's requirements and encouraging competition.

(a) Specifications shall emphasize the functional or performance criteria necessary to meet the needs of the Division.

(3) Persons with a conflict of interest, or who anticipate responding to the proposal for which the specifications are written, may not participate in writing specifications. The Division may retain the services of a person to assist in writing specifications, scopes of work, requirements, qualifications, or other components of a solicitation. However the person assisting in writing specifications shall not, at any time during the procurement process, be employed in any capacity by, nor have an ownership interest in, an individual, public or private corporation, governmental entity, partnership, or unincorporated association bidding on or submitting a proposal in response to the solicitation.

(a) This Rule R23-1-403(3) does not apply to the following:

(i) a design build construction project;

(ii) provisions in specifications provided by the designer when the source of the specification is identified and it is not designed to be an impermissible sole source (a sole source that does not comply with the Utah Procurement Code and the applicable administrative rules); and

(iii) other procurements determined in writing by the Director.

(b) Violations of this Rule R23-1-403(3) may result in:

(i) the bidder or offeror being declared ineligible for award of the contract;

(ii) the solicitation being canceled;

(iii) termination of an awarded contract; or

(iv) any other action determined to be appropriate by the Director.

(4) Brand Name or Equal Specifications.

(a) Brand name or equal specifications may be used when:

(i) "or equivalent" reference is included in the specification; and,

(ii) as many other brand names as practicable are also included in the specification.

(b) Brand name or equal specifications shall include a description of the particular design and functional or performance characteristics which are required. Specifications unique to the brands shall be described in sufficient detail that another person can respond with an equivalent brand.

(c) When a manufacturer's specification is used in a solicitation, the solicitation shall state the minimum acceptable requirements of an equivalent. When practicable, the Division shall name at least three manufacturer's specifications.

(5) Brand Name Sole Source Requirements.

(a) If only one brand can meet the requirement, the Division shall conduct the procurement in accordance with 63G-6a-802 and shall solicit from as many providers of the brand as practicable; and.

(b) If there is only one provider that can meet the requirement, the Division shall conduct the procurement in accordance with Section 63G-6a-802.

 

R23-1-404. Small Purchases (Commodities).

Small purchases shall be conducted in accordance with the requirements set forth in Section 63G-6a-408. This administrative rule provides additional requirements and procedures and must be used in conjunction with the Procurement Code.

(1) "Small Purchase" means a procurement conducted by the Division that does not require the use of a standard procurement process.

(2) Small Purchase thresholds for commodities:

(a) The "Individual Procurement" threshold is a maximum amount of $1,000 for a procurement item;

(i) For individual procurement item(s) costing up to $1,000, the Division may select the best source by direct award and without seeking competitive bids or quotes.

(a) The single procurement aggregate threshold is a maximum amount of $5,000 for multiple procurement item(s) purchased from one source at one time; and

(b) The annual cumulative threshold from the same source is a maximum amount of $50,000.

(3) Whenever practicable, the Division shall use a rotation system or other system designed to allow for competition when using the small purchases process for commodities.

 

R23-1-405. Small Purchases Threshold for Architectural and Engineering Services.

(1) The small purchase threshold for architectural or engineering services is a maximum amount of $100,000.

(2) Architectural or engineering services may be procured up to a maximum of $100,000, by direct negotiation.

(3) The Division shall follow the process described in Section 63G-6a-403 to prequalify potential vendors and Section 63G-6a-404 if the Division develops an approved vendor list, or Part 15 of the Utah Procurement Code for the selection of architectural and engineering services.

(4) The Division shall include minimum specifications when using the small purchase threshold for architectural and engineering services.

 

R23-1-406. Small Purchases Threshold for Construction Projects.

(1) The small construction project threshold is a maximum of $2,500,000 for direct construction costs, including design and allowable furniture or equipment costs;

(2) The Division shall follow the process described in the Section 63G-6a-403 to prequalify potential vendors and Section 63G-6a-404 to develop an Approved Vendor List or other applicable selection methods described in the Utah Procurement Code for construction services.

(3) The Division shall include minimum specifications when using the small purchases threshold for construction projects.

(4) The Director may procure small construction projects up to a maximum of $25,000 by direct award without seeking competitive bids or quotes after documenting that all building code approvals, licensing requirements, permitting, and other construction related requirements are met. The awarded contractor must certify that they are capable of meeting the minimum specifications of the project.

(5) The Director may procure small construction projects costing more than $25,000 up to a maximum of $100,000 by obtaining a minimum of two competitive quotes that include minimum specifications and shall award to the contractor with the lowest quote that meets the specifications after documenting that all applicable building code approvals, licensing requirements, permitting and other construction related requirements are met.

(6) The Division shall procure construction projects over $100,000 using an invitation to bid, request for proposals, approved vendor list, or other approved source selection method provided in the Utah Procurement Code.

 

R23-1-407. Quotes for Small Purchases of Commodities from $1,001 to $50,000.

The following applies to commodities:

(1) For procurement item(s) where the cost is greater than $1,000 but up to a maximum of $5,000, the Division shall obtain a minimum of two competitive quotes, which may be by email, phone or verbal, that include minimum specifications and shall purchase the procurement item from the responsible vendor offering the lowest quote that meets the specifications.

(2) For procurement item(s) where the cost is greater than $5,000 up to a maximum of $50,000, the Division shall obtain a minimum of two competitive quotes, that include minimum specifications, which must be communicated to the proposed vendors in writing, and shall purchase the procurement item from the responsible vendor offering the lowest quote that meets the specifications.

(3) For procurement item(s) costing over $50,000, the Division shall conduct an invitation for bids or other procurement process outlined in the Utah Procurement Code.

(4) The names of the vendors offering quotations and bids and the date and amount of each quotation or bid shall be recorded and maintained as a governmental record.

 

R23-1-408. Small Purchases of Services of Professionals, Providers, and Consultants.

(1) The small purchase threshold for professional service providers and consultants is a maximum amount of $100,000.

(2) After reviewing the qualifications, the Director may obtain professional services or consulting services up to a maximum of $100,000 by direct negotiation.

 

R23-1-501. Request for Information.

In addition to the requirements of Part 5 of the Utah Procurement Code, a Request for Information should indicate the procedure for business confidentiality claims and other protections provided by the Utah Government Records and Access Management Act.

 

R23-1-601. Competitive Sealed Bidding; Multiple Stage Bidding; Reverse Auction.

Competitive Sealed Bidding shall be conducted in accordance with the requirements set forth in Sections 63G-6a-601 through 63G-6a-612. All definitions in the Utah Procurement Code shall apply to this Rule unless otherwise specified in this Rule. This administrative rule provides additional requirements and procedures and must be used in conjunction with the Procurement Code.

 

R23-1-602. Bidder Submissions.

(1) The invitation for bids shall include the information required by Section 63G-6a-603 and shall also include a "Bid Form" or forms, which shall provide lines for each of the following:

(a) the bidder's bid price;

(b) the bidder's acknowledged receipt of addenda issued by the procurement unit;

(c) the bidder to identify other applicable submissions; and (d) the bidder's signature

(2) Bidders may be required to submit descriptive literature and/or product samples to assist the Director in evaluating whether a procurement item meets the specifications and other requirements set forth in the invitation to bid.

(a) Product samples must be furnished free of charge unless otherwise stated in the invitation for bids, and if not destroyed by testing, will upon written request within any deadline stated in the invitation for bids, be returned at the bidder's expense. Samples must be labeled or otherwise identified as specified in the invitation for bids by the procurement unit.

(3) The provisions of Rule R23-1-705 shall apply to protected records.

(4) Bid, payment and performance bonds or other security may be required for procurement items as set forth in the invitation for bids. Bid, payment and performance bond amounts shall be as prescribed by applicable law or must be based upon the estimated level of risk associated with the procurement item and may not be increased above the estimated level of risk with the intent to reduce the number of qualified bidders.

 

R23-1-603. Pre-Bid Conferences and Site Visits.

(1) Except as authorized in writing by the Director, pre-bid conferences and site visits must require mandatory attendance by all bidders.

(a) A pre-bid conference may be attended via the following:

(i) attendance in person;

(ii) teleconference participation;

(iii) webinar participation;

(iv) participation through other electronic media approved by the Director.

(b) Mandatory site visits must be attended in person.

(c) All pre-bid conferences and site visits must be attended by an authorized representative of the person or vendor submitting a bid and as may be further specified in the procurement

documents.

(d) The solicitation must state that failure to attend a mandatory pre-bid conference shall result in the disqualification of any bidder that does not have an authorized representative attend the entire duration of the mandatory pre-bid conference.

(e) The solicitation must state that failure to attend a mandatory site visit shall result in the disqualification of any bidder that does not have an authorized representative attend the entire

duration of the mandatory site visit.

(f) At the discretion of the conducting procurement unit, audio or video recordings of pre-bid conferences and site visits may be used.

(g) Listening to or viewing audio or video recordings of a mandatory pre-bid conference or site visit may not be substituted for attendance.

(2) If a pre-bid conference or site visit is held, the Division shall maintain:

(a) an attendance log including the name of each attendee, the entity the attendee is representing, and the attendee's contact information;

(b) minutes, if there are any, of the pre-bid conference or site visit;

(c) copies of any documents distributed by the Division to the attendees at the pre-bid conference or site visit; and

(d) any verbal modifications made to any of the solicitation documents. All verbal modifications to the solicitation documents shall be reduced to writing.

(3) The Division shall publish as an Addendum to the solicitation, the information in R23-1-603 (2)(a) above.

 

R23-1-604. Addenda to Invitation for Bids.

Prior to the submission of bids, a procurement unit may issue addenda which may modify any aspect of the Invitation for Bids.

(1) Addenda shall be distributed within a reasonable time to allow prospective bidders to consider the addenda in preparing bids.

(2) After the due date and time for submitting bids, at the discretion of the Director, addenda to the Invitation for Bids may be limited to bidders that have submitted bids, provided the addenda does not make a substantial change to the Invitation for Bids that, in the opinion of the Director, likely would have impacted the number of bidders responding to the Invitation for Bids.

 

R23-1-605. Bids and Modifications to a Bid Received After the Due Date and Time.

(1) Bids and modifications to a bid submitted electronically or by physical delivery, after the established due date and time, will not be accepted for any reason, except as determined in R23-1-605(4).

(2) When submitting a bid or modification electronically, bidders must allow sufficient time to complete the online forms and upload documents. The solicitation will end at the closing time posted in the electronic system. If a bidder is in the middle of uploading a bid when the closing time arrives, the system will stop the process and the bid or modification to the bid will not be accepted.

(3) When submitting a bid or modification to a bid by physical delivery (U.S. Mail, courier service, hand-delivery, or other physical means) bidders are solely responsible for meeting the deadline. Delays caused by a delivery service or other physical means will not be considered as an acceptable reason for a bid or modification to a bid being late.

(4) All bids or modifications to bids received by physical delivery will be date and time stamped by the procurement unit.

(5) To the extent that an error on the part of the Division results in a bid or modification to a bid not being received by the established due date and time, the bid or modification to a bid shall be accepted as being on time.

 

R23-1-606. Errors in Bids.

The following shall apply to the correction or withdrawal of an inadvertently erroneous bid, or the cancelation of an award or contract that is based on an unintentionally erroneous bid. A decision to permit the correction or withdrawal of a bid or the cancellation of any award or a contract under this Rule shall be supported in a written document, signed by the Director.

(1) Errors attributed to a bidder's error in judgment may not be corrected.

(2) Provided that there is no change in bid pricing or the cost evaluation formula, errors not attributed to a bidder's error in judgment may be corrected if it is in the best interest of the procurement unit and correcting the mistake maintains the fair treatment of other bidders.

(a) Examples include:

(i) missing signatures,

(ii) missing acknowledging receipt of an addendum;

(iii) missing copies of professional licenses, bonds, insurance certificates, provided that copies are submitted by the deadline established by the Director to correct this mistake;

(iv) typographical errors;

(v) mathematical errors not affecting the total bid price; or (vi) other errors deemed by the Director to be immaterial or inconsequential in nature.

(3) The Director shall approve or deny, in writing, a bidder's request to correct or withdraw a bid.

(4) Corrections or withdrawal of bids shall be conducted in accordance with Section 63G-6a-605.

(5) If there is any deficiency or failure to submit a required sublist and/or "bid" bond, the Division may request that the bidder who is not in compliance, submit the required sublist and/or "bid" bond by 5 p.m. of the next business day after notice is provided by the Division. Failure to cure the deficiency or failure to submit any required sublist and/or "bid" bond by 5:00 p.m. of the next business day after notice is provided by the Division shall make the bidder ineligible for consideration of award of the contract.

 

R23-1-607. Errors Discovered After the Award of Contract.

(1) Errors discovered after the award of a contract may only be corrected if, after consultation with the Director and the attorney general's office, it is determined that the correction of the mistake does not violate the requirements of the Utah Procurement Code or these administrative rules.

(2) Any correction made under this subsection must be supported by a written determination signed by the Director.

 

R23-1-608. Re-solicitation of a Bid.

(1) Re-solicitation of a bid may occur only if the Director determines that:

(a) A material change in the scope of work or specifications has occurred;

(b) procedures outlined in the Utah Procurement Code were not followed;

(c) additional public notice is desired;

(d) there was a lack of adequate competition; or

(e) other reasons exist that are in the best interests of the procurement unit.

(2) Re-solicitation may not be used to avoid awarding a contract to a qualified vendor in an attempt to steer the award of a contract to a favored vendor.

 

R23-1-609. Only One Bid Received.

(1) If only one responsive and responsible bid is received in response to an Invitation for Bids, including multiple stage bidding, an award may be made to the single bidder if the Director determines that the price submitted is fair and reasonable, and that other prospective bidders had a reasonable opportunity to respond, or there is not adequate time for re-solicitation. Otherwise, the bid may be rejected and:

(a) a new invitation for bids solicited;

(b) the procurement canceled; or

(c) the procurement may be conducted as a sole source under Section 63G-6a-802.

 

R23-1-610. Multiple or Alternate Bids.

(1) Multiple or alternate bids will not be accepted, unless otherwise specifically required or allowed in the invitation for bids.

(2) If a bidder submits multiple or alternate bids that are not requested in the invitation for bids, the Director will only accept the bidder's primary bid and will not accept any other bids constituting multiple or alternate bids.

 

R23-1-611. Methods to Resolve Tie Bids.

(1) In accordance with Section 63G-6a-608, in the event of tie bids, the contract shall be awarded to the procurement item offered by a Utah resident bidder, provided the bidder indicated on the invitation to bid form that it is a Utah resident bidder.

(2) If a Utah resident bidder is not identified, an acceptable method when there are two tie bids shall be for the Director to toss a coin in the presence of a minimum of three witnesses with the firm first in alphabetical order being "heads."

(3) Other methods to resolve a tie bid described in Section 63G-6a-608 may be used as deemed appropriate by the Director.

 

R23-1-612. Publication of Award.

(1) The Division shall, on the day on which the award of a contract is announced, make available to each bidder and to the public a notice that includes:

(a) the name of the bidder to which the contract is awarded and the price(s) of the procurement item(s); and

(b) the names and the prices of each bidder to which the contract is not awarded.

 

R23-1-613. Multiple Stage Bidding Process.

Multiple stage bidding shall be conducted in accordance with the requirements set forth in Section 63G-6a-609, Utah Procurement Code.

(1) The Director may hold a pre-bid conference as described in Rule R33-6-103 to discuss the multiple stage bidding process or for any other permissible purpose.

 

R23-1-614. Technology Acquisitions.

(1) The Division in an Invitation for Bids may state that at any time during the term of a contract, that the Division may undertake a review in consultation with the Utah Technology Advisory Board and the Department of Technology Services to determine whether a new technology exists that is in the best interest of the acquiring agency, taking into consideration cost, life-cycle, references, current customers, and other factors and that the acquiring agency reserves the right to:

(a) negotiate with the contractor for the new technology, provided the new technology is substantially within the original scope of work;

(b) terminate the contract in accordance with the existing contract terms and conditions; or

(c) conduct a new procurement for an additional or supplemental contract as needed to take into account new technology.

(2) Subject to the provisions of Section 63G-6a-802, the trial use or testing of new technology may be permitted for a duration not to exceed the maximum time necessary to evaluate the technology.

 

R23-1-615. Subcontractor Lists.

The Division may not consider, or award to, any bid submitted by a bidder if the bidder fails to submit a subcontractor list meeting the requirements of Section 63A-5-208 and this Rule. For purposes of this Rule R23-1-615, the definitions of Section 63A-5-208 shall be applicable. Within 24 hours after the bid opening time, not including Saturdays, Sundays and state holidays, the apparent lowest three bidders, as well as other bidders that desire to be considered, shall submit to the Division a list of their first-tier subcontractors that are in excess of the dollar amounts stated in Subsection 63A-5-208(3)(a)(i)(A).

(1) The subcontractor list shall include the following:

(a) the type of work the subcontractor is to perform;

(b) the subcontractor's name;

(c) the subcontractor's bid amount;

(d) the license number of the subcontractor issued by the Utah Division of Occupational and Professional Licensing, if such license is required under Utah law; and

(e) the impact that the selection of any alternate included in the solicitation would have on the information required by this Subsection (14).

(2) The contract documents for a specific project may require that additional information be provided regarding any contractor, subcontractor, or supplier.

(3) If pursuant to Subsection 63A-5-208(4), a bidder intends to perform the work of a subcontractor or obtain, at a later date, a bid from a qualified subcontractor, the bidder shall:

(a) comply with the requirements of Section 63A-5-208 and

(b) clearly list himself/herself on the subcontractor list form.

(4) Errors on the subcontractor list will not disqualify the bidder if the bidder can demonstrate that the error is a result of his reasonable reliance on information that was provided by the subcontractor and was used to meet the requirements of this section, and, provided that this does not result in an adjustment to the bidder's contract amount.

(5) Pursuant to Sections 63A-5-208 and 63G-2-305, information contained in the subcontractor list submitted to the Division shall be classified public except for the amount of subcontractor bids which shall be classified as protected until a contract has been awarded to the bidder at which time the subcontractor bid amounts shall be classified as public. During the time that the subcontractor bids are classified protected, they may only be made available to procurement and other officials involved with the review and approval of bids.

(6) Change of Listed Subcontractors. Subsequent to twenty-four hours after the bid opening, the contractor may change his listed subcontractors only after receiving written permission from the Director based on complying with all of the following:

(a) The contractor has established in writing that the change is in the best interest of the State and that the contractor establishes an appropriate reason for the change, which may include, but is not limited to, the following reasons:

(i) the original subcontractor has failed to perform, or is not qualified or capable of performing

(ii) the subcontractor has requested in writing to be released

(b) The circumstances related to the request for the change do not indicate any bad faith in the original listing of the subcontractors;

(c) Any requirement set forth by the Director to ensure that the process used to select a new subcontractor does not give rise to bid shopping;

(d) Any increase in the cost of the subject subcontractor work shall be borne by the contractor; and

(e) Any decrease in the cost of the subject subcontractor work shall result in a deductive change order being issued for the contract for such decreased amount.

 

R23-1-616. Bids Over Budget.

(1) In the event all bids for a construction project exceed available funds as certified by the appropriate fiscal officer, and the low responsive and responsible bid does not exceed those funds by more than 5%, the Director may, where time or economic considerations preclude resolicitation of work of a reduced scope, negotiate an adjustment of the bid price, including changes in the bid requirements, with the low responsive and responsible bidder in order to bring the bid within the amount of available funds.

(2) As an alternative to the procedure authorized in Subsection (1), when all bids for a construction project exceed available funds as certified by the Director, and the Director finds that due to time or economic considerations the re-solicitation of a reduced scope of work would not be in the interest of the state, the Director may negotiate an adjustment in the bid price using one of the following methods:

(a) reducing the scope of work in specific subcontract areas and supervising the re-bid of those subcontracts by the low responsive and responsible bidder;

(b) negotiating with the low responsive and responsible bidder for a reduction in scope and cost with the value of those reductions validated in accordance with Section R23-1-50; or

(c) revising the contract documents and soliciting new bids only from bidders who submitted a responsive bid on the original solicitation. This re-solicitation may have a shorter bid response time than otherwise required.

(3) The use of one of the alternative procedures provided for in this subsection (2) must provide for the fair and equitable treatment of bidders.

(4) The Director's written determination, including a brief explanation of the basis for the decision shall be included in the contact file.

(5) This Rule does not restrict in any way, the right of the Director to use any emergency or sole source procurement provisions, or any other applicable provisions of State law or rule which may be used to award the construction project.

 

R23-1-701. Conducting the Request for Proposals Standard Procurement Process.

Request for Proposals shall be conducted in accordance with the requirements set forth in Sections 63G-6a-701 through 63G-6a-711, Utah Procurement Code. All definitions in the Utah Procurement Code shall apply to this Rule unless otherwise specified in this Rule. This administrative rule provides additional requirements and procedures and must be used in conjunction with the Procurement Code.

 

R23-1-702. Content of the Request for Proposals.

(1) In addition to the requirements set forth under Section 63G-6a-703, the request for proposals solicitation shall include:

(a) a description of the format that offerors are to use when submitting a proposal including any required forms; and

(b) instructions for submitting price.

(2) The Division is responsible for all content contained in the request for proposals solicitation documents, including:

(a) reviewing all schedules, dates, and timeframes;

(b) approving content of attachments;

(c) providing the Division with redacted documents, as applicable;

(d) assuring that information contained in the solicitation documents is public information; and

(e) understanding the scope of work, all evaluation criteria, requirements, factors, and formulas to be used in determining the scoring of proposals; and

(f) the requirements of Section 63G-6a-402(6).

 

R23-1-703. Multiple Stage RFP Process.

(1) In addition to the requirements set forth under Section 63G-6a-710, the multiple stage request for proposals solicitation shall include:

(a) a description of the stages and the criteria and scoring that will be used to evaluate proposals at each stage; and

(b) the methodology used to determine which proposals shall be disqualified from additional stages.

 

R23-1-704. (Reserved for Expansion).

Reserved.

 

R23-1-705. Protected Records.

(1) The following are protected records and may be redacted by the vendor subject to the procedures described below in accordance with the Governmental Records Access and Management Act (GRAMA) Title 63G, Chapter 2 of the Utah Code.

(a) Trade Secrets, as defined in Section 13-24-2 of the Utah Code.

(b) Commercial information or non-individual financial information subject to the provisions of Section 63G-2-305(2).

(c) Other Protected Records under GRAMA.

(2) Process For Requesting Non-Disclosure. Any person requesting that a record be protected shall include with the proposal or submitted document:

(a) a written indication of which provisions of the proposal or submitted document are claimed to be considered for business confidentiality or protected (including trade secrets or other reasons for non-disclosure under GRAMA); and

(b) a concise statement of the reasons supporting each claimed provision of business confidentiality or protected.

 

R23-1-706. Notification.

(1) A person who complies with Rule R23-1-705 shall be notified by the procurement unit prior to the public release of any information for which a claim of confidentiality has been asserted.

(2) Except as provided by court order, the procurement unit to whom the request for a record is made under GRAMA, may not disclose a record claimed to be protected under Rule R23-1-705 but which the procurement unit or State Records Committee determines should be disclosed until the period in which to bring an appeal expires or the end of the appeals process, including judicial appeal, is reached. This Rule R23-1-706 does not apply where the claimant, after notice, has waived the claim by not appealing or intervening before the State Records Committee. To the extent allowed by law, the parties to a dispute regarding the release of a record may agree in writing to an alternative dispute resolution process.

(3) Any allowed disclosure of public records submitted in the request for proposal process will be made only after the selection of the successful offeror(s) has been made public in compliance with Section 63G-6a-709.5.

 

R23-1-707. Process for Submitting Proposals with Protected Business Confidential Information.

(1) If an offeror submits a proposal that contains information claimed to be business confidential or protected information, the offeror must submit two separate proposals:

(a) One redacted version for public release, with all protected business confidential information either blacked-out or removed, clearly marked as "Redacted Version"; and

(b) One non-redacted version for evaluation purposes clearly marked as "Protected Business Confidential."

(i) Pricing may not be classified as business confidential and will be considered public information.

(ii) An entire proposal may not be designated as "PROTECTED", "CONFIDENTIAL" or "PROPRIETARY" and shall be considered non-responsive unless the offeror removes the designation.

 

R23-1-708. Pre-Proposal Conferences and Site Visits.

(1) Except as authorized in writing by the Director, pre-proposal conferences and site visits must require mandatory attendance by all offerors.

(a) A pre-proposal conference may be attended via the following:

(i) attendance in person;

(ii) teleconference participation;

(iii) webinar participation;

(iv) participation through other electronic media approved by the Director.

(b) Mandatory site visits must be attended in person.

(c) All pre-proposal conferences and site visits must be attended by an authorized representative of the person or vendor submitting a proposal and as may be further specified in the procurement documents.

(d) The solicitation must state that failure to attend a mandatory pre-proposal conference shall result in the disqualification of any offeror that does not have an authorized representative attend the entire duration of the mandatory pre-proposal conference.

(e) The solicitation must state that failure to attend a mandatory site visit shall result in the disqualification of any offeror that does not have an authorized representative attend the entire duration of the mandatory site visit.

(f) At the discretion of the conducting procurement unit, audio or video recordings of pre-proposal conferences and site visits may be used.

(g) Listening to or viewing audio or video recordings of a mandatory pre-proposal conference or site visit may not be substituted for attendance.

(2) If a pre-proposal conference or site visit is held, the Division unit shall maintain:

(a) an attendance log including the name of each attendee, the entity the attendee is representing, and the attendee's contact information;

(b) minutes, if there are any, of the pre-proposal conference or site visit;

(c) copies of any documents distributed by the Division to the attendees at the pre-proposal conference or site visit:

(d) any verbal modification made to any of the solicitation documents. All verbal modifications to the solicitation documents shall be reduced to writing.

(3) The Division shall publish as an addendum to the solicitation, the information in R23-1-708(2)(a) above.

 

R23-1-709. Addenda to Request for Proposals.

(1) Addenda to the Request for Proposals may be made for the purpose of:

(a) making changes to:

(i) the scope of work;

(ii) the schedule;

(iii) the qualification requirements;

(iv) the criteria;

(v) the weighting; or

(vi) other requirements of the Request for Proposal.

(b) Addenda shall be published within a reasonable time prior to the deadline that proposals are due, to allow prospective offerors to consider the addenda in preparing proposals. Publication at least 5 calendar days prior to the deadline that proposals are due shall be deemed a reasonable time. Minor addenda and urgent circumstances may require a shorter period of time.

(2) After the due date and time for submitting a response to Request for Proposals, at the discretion of the Director, addenda to the Request for Proposals may be limited to offerors that have submitted proposals, provided the addenda does not make a substantial change to the Request for Proposals that, in the opinion of the Director likely would have impacted the number of Offerors responding to the original publication of the Request for Proposals.

 

R23-1-710. Modification or Withdrawal of Proposal Prior to Deadline.

A proposals may be modified or withdrawn prior to the established due date and time for responding.

 

R23-1-711. Proposals and Modifications, Delivery and Time Requirements.

(1) Except as provided in R23-1-711(5) below, proposals and modifications to a proposal submitted electronically or by physical delivery, after the established due date and time, will not be accepted for any reason.

(2) When submitting a proposal or modification to a proposal electronically, offerors must allow sufficient time to complete the online forms and upload documents. The solicitation will end at the closing time posted in the electronic system. If an offeror is in the middle of uploading a proposal when the closing time arrives, the system should stop the process and the proposal or modification to a proposal will not be accepted.

(3) When submitting a proposal or modification to a proposal by physical delivery (U.S. Mail, courier service, hand-delivery, or other physical means) offerors are solely responsible for meeting the deadline. Delays caused by a delivery service or other physical means will not be considered as an acceptable reason for a proposal or modification to a proposal being late.

(4) All proposals or modifications to proposals received by physical delivery will be date and time stamped by the Division.

(5) To the extent that an error on the part of the Division results in a proposal or modification to a proposal not being received by the established due date and time, the proposal or modification to a proposal shall be accepted as being on time.

 

R23-1-712. Errors in Proposals.

The following shall apply to the correction or withdrawal of an unintentionally erroneous proposal, or the cancellation of an award or contract that is based on an unintentionally erroneous proposal. A decision to permit the correction or withdrawal of a proposal or the cancellation of an award or a contract shall be supported in a written document, signed by the Director.

(1) Mistakes attributed to an offeror's error in judgment may not be corrected.

(2) Unintentional errors not attributed to an offeror's error in judgment may be corrected if it is in the best interest of the procurement unit and correcting the error maintains the fair treatment of other offerors.

(a) Examples include:

(i) missing signatures,

(ii) missing acknowledgement of an addendum;

(iii) missing copies of professional licenses, bonds, insurance certificates, provided that copies are submitted by the deadline established by the Director to correct this mistake;

(iv) typographical errors;

(v) mathematical errors not affecting the total proposed price; or

(vi) other errors deemed by the Director to be immaterial or inconsequential in nature.

(3) Unintentional errors discovered after the award of a contract may only be corrected if, after consultation with the Director and the Attorney General's Office, it is determined that the correction of the error does not violate the requirements of the Utah Procurement Code or these administrative rules.

 

R23-1-713. Evaluation of Proposals.

The evaluation of proposals shall be conducted in accordance with Part 7 of the Utah Procurement Code.

 

R23-1-714. Correction or Withdrawal of Proposal, Sublist and Bond errors.

(1) In the event an offeror submits a proposal that on its face appears to be impractical, unrealistic or otherwise in error, the Director may contact the offeror to either confirm the proposal, permit a correction of the proposal, or permit the withdrawal of the proposal, in accordance with Section 63G-6a-706.

(2) Offerors may not correct errors, deficiencies, or incomplete responses in a proposal that has been determined to be not responsible, not responsive, or that does not meet the mandatory minimum requirements stated in the request for proposals in accordance with Section 63G-6a-704.

(3) If there is any deficiency or failure to submit a required sublist and/or "bid" bond, the Division may request that the offeror who is not in compliance, submit the required sublist and/or "bid" bond by 5 p.m. of the next business day after notice is provided by the Division. Failure to cure the deficiency or failure to submit any required sublist and/or "bid" bond by 5:00 p.m. of the next business day after notice is provided by the Division shall make the offeror ineligible for consideration of award of the contract.

 

R23-1-715. Interviews and Presentations.

(1) Interviews and presentations may be held as outlined in the RFP.

(2) Offerors invited to interviews or presentations shall be limited to those offerors meeting minimum requirements specified in the RFP.

(3) Representations made by the offeror during interviews or presentations shall become an addendum to the offeror's proposal and shall be documented. Representations must be consistent with the offeror's original proposal and may only be used for purposes of clarifying or filling in gaps in the offeror's proposal.

(4) The Director shall establish a date and time for the interviews or presentations and shall notify eligible offerors of the procedures. Interviews and presentations will be at the offeror's expense.

 

R23-1-716. Best and Final Offers.

Best and Final Offers shall be conducted in accordance with Section 63G-6a-707.5. This administrative rule provides additional requirements and procedures and must be used in conjunction with the Procurement Code.

(1) The best and final offers (BAFO) process is an optional step in the evaluation phase of the request for proposals process in which offerors are requested to modify their proposals.

(a) An evaluation committee may request best and final offers when:

(i) no single proposal addresses all the specifications;

(ii) all or a significant number of the proposals received are unclear and the evaluation committee requires further clarification;

(iii) additional information is needed in order for the evaluation committee to make a decision;

(iv) the differences between proposals in one or more categories are too slight to distinguish;

(v) all cost proposals are too high or over the budget;

(vi) multiple contract awards are necessary to achieve regional or statewide coverage for a procurement item under an RFP and there are insufficient cost proposals within the budget to award the number of contracts needed to provide regional or statewide coverage.

(2) Only offerors meeting the minimum qualifications or scores described in the RFP are eligible to respond to best and final offers.

(3) Proposal modifications submitted in response to a request for best and final offers may only address the specific issues and/or sections of the RFP described in the request for best and final offers.

(a) Offerors may not use the best and final offers process to correct deficiencies in their proposals not addressed in the request for best and final offers issued by the Division.

(4) When a request for best and final offers is issued to reduce cost proposals, offerors shall submit itemize cost proposals clearly indicating the tasks or scope reductions that can be accomplished to bring costs within the available budget.

(a) The cost information of one offeror may not be disclosed to competing offerors during the best and final offers process and further, such cost information shall not be shared with other offerors until the contract is awarded.

(b) The Division shall ensure that auction tactics are not used in the discussion process, including discussing and comparing the costs and features of other proposals.

(5) The best and final offers process may not be conducted as part of the contract negotiation process. It may only be conducted during the evaluation phase of the RFP process.

(6) A procurement unit may not use the best and final offers process to allow offerors a second opportunity to respond to the entire request for proposals.

(7) If a proposal modification is made orally during the interview or presentation process, the modification must be confirmed in writing.

(8) A request for best and final offers issued by the Division shall:

(a) comply with all public notice requirements provided in Section 63G-6a-406;

(b) include a deadline for submission that allows offerors a reasonable opportunity for the preparation and submission of their responses;

(c) indicate how proposal modifications in response to a request for best and final offers will be evaluated;

(9) If an offeror does not submit a best and final offer, its immediately previous proposal will be considered its best and final offer;

(10) Unsolicited best and final offers will not be accepted from offerors.

 

R23-1-717. Cost-benefit Analysis Exception: CM/GC.

(1) A cost-benefit analysis is not required if the contract is awarded solely on the qualifications of the construction manager/general contractor and the management fee described in Section 63G-6a-708 provided:

(a) a competitive process is maintained by the issuance of a request for proposals that requires the offeror to provide, at a minimum:

(i) a management plan;

(ii) references;

(iii) statements of qualifications; and

(iv) a management fee only if requested by the Division. The management fee may not be requested by the Division if the management fee is not part of the criteria for the evaluation committee. The Division may use a fee table for this management fee.

(b) the management fee contains only the following:

(i) preconstruction phase services;

(ii) monthly supervision fees for the construction phase; and

(iii) overhead and profit for the construction phase.

(c) the evaluation committee may, as described in the solicitation, weight and score the management fee as a fixed rate or a fixed percentage of the estimated contract value.

(d) the contract awarded must be in the best interest of the procurement unit.

 

R23-1-718. Only One Proposal Received.

(1) If only one proposal is received in response to a request for proposals, the evaluation committee may:

(a) conduct a review to determine if:

(i) the proposal meets the minimum requirements;

(ii) pricing and terms are reasonable; and

(iii) the proposal is in the best interest of the procurement unit.

(b) if the evaluation committee determines the proposal meets the minimum requirements, pricing and terms are reasonable, and the proposal is in the best interest of the procurement unit, the procurement unit may make an award.

(c) If an award is not made, the procurement unit may either cancel the procurement or re-solicit for the purpose of obtaining additional proposals.

 

R23-1-719. Publicizing Awards.

(1) In addition to the requirements of Section 63G-6a-709.5, the following shall be disclosed after receipt of a GRAMA request and payment of any lawfully enacted and applicable fees:

(a) the contract(s) entered into as a result of the selection and the successful proposal(s), except for those portions that are to be non-disclosed under Rule R23-1-705;

(b) the unsuccessful proposals, except for those portions that are to be non-disclosed under Rule R23-1-705;

(c) the rankings of the proposals;

(d) the names of the members of any selection committee (reviewing authority);

(e) the final scores used by the selection committee to make the selection, except that the names of the individual scorers shall not be associated with their individual scores or rankings.

(f) the written justification statement supporting the selection, except for those portions that are to be non-disclosed under Rule R23-1-705.

(2) After due consideration and public input, the following has been determined by the Board to impair governmental procurement proceedings or give an unfair advantage to any person proposing to enter into a contract or agreement with a governmental entity, and will not be disclosed by the governmental entity at any time to the public including under any GRAMA request:

(a) the names of individual scorers/evaluators in relation to their individual scores or rankings;

(b) any individual scorer's/evaluator's notes, drafts, and working documents;

(c) non-public financial statements; and

(d) past performance and reference information, which is not provided by the offeror and which is obtained as a result of the efforts of the governmental entity. To the extent such past performance or reference information is included in the written justification statement; it is subject to public disclosure.

 

R23-1-801. Sole Source - Award of Contract Without Competition.

(1) Sole source procurements shall be conducted in accordance with the requirements set forth in Section 63G-6a-802, Utah Procurement Code. All definitions in the Utah Procurement Code shall apply to this Rule unless otherwise specified in this Rule. This administrative rule provides additional requirements and procedures and should be used in conjunction with the Procurement Code.

(2) A sole source procurement may be conducted if:

(a) there is only one source for the procurement item;

(b) the award to a specific supplier, service provider, or contractor is a condition of a donation or grant that will fund the full cost of the supply, service, or construction item; or

(c) the procurement item is needed for trial use or testing to determine whether the procurement item will benefit the procurement unit.

(3) An urgent or unexpected circumstance or requirement for a procurement item does not justify the award of a sole source procurement.

(4) Requests for a procurement to be conducted as a sole source shall be submitted in writing to the Director for approval.

(5) The sole source request shall be submitted to the Director and shall include:

(a) a description of the procurement item;

(b) the total dollar value of the procurement item, including, when applicable, the actual or estimated full lifecycle cost of maintenance and service agreements;

(c) the duration of the proposed sole source contract;

(d) an authorized signature of the requester;

(e) unless the sole source procurement is conducted under Rule R23-1-801(2)(b) or (c), research completed by the requester documenting that there are no other competing sources for the procurement item;

(f) any other information requested by the Director; and

(6) a sole source request form containing all of the requirements of Rule R23-1-801(5) may be available on the division's website and/or may be described in specifications or other contract documents.

(7) Except as provided in (b), sole source procurements over $50,000 shall be published in accordance with Section 63G-6a-406.

(a) Sole source procurements under $50,000 are not required to be published but may be published at the discretion of the Director.

(b) The requirement for publication of notice for a sole source procurement is waived:

(i) for public utility services;

(ii) if the award to a specific supplier, service provider, or contractor is a condition of a donation or grant that will fund the full cost of the supply, service, or construction item;

(iii) when the circumstances of the request are clear that there can only be one source; or

(iv) for other circumstances as determined in writing by the Director.

(8) A person may contest a sole source procurement prior to the closing of the public notice period set forth in Section 63G-6a-406, when public notice is required under this Rule R23-1-801 by submitting the following information in writing to the Director:

(a) the name of the contesting person; and

(b) a detailed explanation of the challenge, including documentation showing that there are other competing sources for the procurement item.

(9) Upon receipt of information contesting a sole source procurement, the Director shall conduct an investigation to determine the validity of the challenge and make a written determination either supporting or denying the challenge.

 

R23-1-802. Trial Use or Testing of a Procurement Item, Including New Technology.

The trial use or testing of a procurement item, including new technology, shall be conducted as set forth in Section 63G-6a-802, Utah Procurement Code.

 

R23-1-803. Alternative Procurement Methods.

(1) The Director may utilize alternative procurement methods to acquire procurement items such as those listed below when it is determined in writing by the Director, to be more practicable or advantageous to the procurement unit:

(a) used vehicles;

(b) livestock;

(c) hotel conference facilities and services;

(d) speaker honorariums;

(e) hosting out-of-state and international dignitaries;

(f) international promotion of the state; and

(g) any other procurement item for which a standard procurement method is not reasonably practicable.

(2) When making this determination, the Director may take into consideration whether:

(a) the potential cost of preparing, soliciting and evaluating bids or proposals is expected to exceed the benefits normally associated with such solicitations;

(b) the procurement item cannot be acquired through a standard procurement process; and

(c) the price of the procurement item is fair and reasonable.

(3) In the event that it is so determined, the Director may elect to utilize an alternative procurement method which may include any or all of the following:

(a) informal price quotations;

(b) direct negotiations; and

(c) direct award.

 

R23-1-804. Emergency Procurement.

(1) Emergency procurements shall be conducted in accordance with the requirements set forth in Section 63G-6a-803, and this rule.

(2) An emergency procurement is a procurement procedure where the procurement unit is authorized to obtain a procurement item without using a standard competitive procurement process.

(3) Emergency procurements are limited to those procurement items necessary to mitigate the emergency.

(4) While a standard procurement process is not required under an emergency procurement, when practicable, the Division should seek to obtain as much competition as possible through use of phone quotes, internet quotes, limited invitations to bid, or other selection methods while avoiding harm, or risk of harm, to the public health, safety, welfare, property, or impairing the ability of a public entity to function or perform required services.

(5) The Division shall make a written determination documenting the basis for the emergency and the selection of the procurement item. A record of the determination and selection shall be kept in the contract file. The documentation may be made after the emergency condition has been alleviated.

 

R23-1-805. Declaration of "Official State of Emergency".

Upon a declaration of an "Official State of Emergency" by the authorized state official, the Director shall implement the division's Continuity of Operations Plan, or COOP. When activated, the division shall follow the procedures outlined in the plan and take appropriate actions as directed by the procurement unit responsible for authorizing emergency acquisitions of procurement items.

 

R23-1-901. General Provisions.

(1) An Invitation for Bids, a Request for Proposals, or other solicitation may be canceled prior to the deadline for receipt of bids, proposals, or other submissions, when it is in the best interests of the procurement unit as determined by the Division. In the event a solicitation is cancelled, the reasons for cancellation shall be made part of the procurement file and shall be available for public inspection and the Division shall:

(a) re-solicit new bids or proposals using the same or revised specifications; or,

(b) withdraw the requisition for the procurement item(s).

 

R23-1-902. Re-solicitation.

(1) In the event there is no initial response to an initial solicitation, the Director may:

(a) contact the known supplier community to determine why there were no responses to the solicitation;

(b) research the potential vendor community; and,

(c) based upon the information in (a) and (b) require the Division to modify the solicitation documents.

(2) If the Division has modified the solicitation documents and after the re-issuance of a solicitation, there is still no competition or there is insufficient competition, the Director, shall:

(a) require the Division to further modify the procurement documents; or,

(b) cancel the requisition for the procurement item(s).

 

R23-1-903. Cancellation Before Award.

(1) Solicitations may be cancelled before award but after opening all bids or offers when the Director determines in writing that:

(a) inadequate or ambiguous specifications were cited in the solicitation;

(b) the specifications in the solicitation have been or must be revised;

(c) the procurement item(s) being solicited are no longer required;

(d) the solicitation did not provide for consideration of all factors of cost to the procurement unit, such as cost of transportation, warranties, service and maintenance;

(e) bids or offers received indicate that the needs of the procurement unit can be satisfied by a less expensive procurement item differing from that in the solicitation;

(f) except as provided in Section 63G-6a-607, all otherwise acceptable bids or offers received are at unreasonable prices, or only one bid or offer is received and the Director cannot determine the reasonableness of the bid price or cost proposal;

(g) the responses to the solicitation were not independently arrived at in open competition, were collusive, or were submitted in bad faith; or,

(h) no responsive bid or offer has been received from a responsible bidder or offer;


R23-1-904. Alternative to Cancellation.

In the event administrative difficulties are encountered before award but after the deadline for submissions that may delay award beyond the bidders' or offerors' acceptance periods, the bidders or offerors should be requested, before expiration of their bids or offers, to extend in writing the acceptance period (with consent of sureties, if any) in order to avoid the need for cancellation.


R23-1-905. Continuation of Need.

If the solicitation has been cancelled for the reasons specified in Rule R23-1-903 (1)(f), (g) or (h) and the Director has made the written determination in Rule R23-1-903(1) and the Division has an existing contract, the Division may permit an extension of the existing contract under Section 63G-6a-802(7).

 

R23-1-906. Rejections and Suspension/Debarment.

(1) The Division may reject any or all bids, offers or other submissions, in whole or in part, as may be specified in the solicitation, when it is in the best interest of the procurement unit. In the event of a rejection of any or all bids, offers or other submissions, in whole or in part, the reasons for rejection shall be made part of the procurement file and shall be available for public inspection.

(2) Bids, offers, or other submissions, received from any person that is suspended, debarred, or otherwise ineligible as of the due date for receipt of bids, proposals, or other submissions shall be rejected.

 

R23-1-907. Rejection for Nonresponsibility or Nonresponsiveness.

(1) Subject to Section 63G-6a-903, the Director shall reject a bid or offer from a bidder or offeror determined to be nonresponsible. A responsible bidder or offeror is defined in Section 63G-6a-103(42).

(2) In accordance with Section 63G-6a-604(3) the Director may not accept a bid that is not responsive. Responsiveness is defined in Section 63G-6a-103(43).

(3) If there is any deficiency or failure to submit a required sublist and/or "bid" bond, the Division may request that the bidder/offeror who is not in compliance, submit the required sublist and/or "bid" bond by 5 p.m. of the next business day after notice is provided by the Division. Failure to cure the deficiency or failure to submit any required sublist and/or "bid" bond by 5:00 p.m. of the next business day after notice is provided by the Division, shall make the bidder/offeror nonresponsive and therefore ineligible for consideration of award of the contract.

(4) The originals of all rejected bids, offers, or other submissions, and all written findings with respect to such rejections, shall be made part of the procurement file and available for public inspection.

 

R23-1-908. Debarment or Suspension From Consideration for Award of Contracts -- Process -- Causes for Debarment -- Appeal.

The procedures for a debarment or suspension from consideration for award of contracts, including appellate rights, are provided in Section 63G-6a-904. Upon any suspension or debarment, the person that is suspended or debarred shall be considered nonresponsible and ineligible for the award of contracts by the Division in accordance with the determination of suspension or debarment.

 

R23-1-1001. Providers of State Products.

(1) In addition to the reciprocal preference requirements contained in Section 63G-6a-1002 for the providers of procurement items produced, manufactured, mined, grown, or performed in Utah, Rule R23-1-10 outlines the process for award of a contract when there is more than one equally low preferred bidder. All definitions in the Utah Procurement Code shall apply to this Rule unless otherwise specified in this Rule. This administrative rule provides additional requirements and procedures and must be used in conjunction with the Procurement Code.

(2) In the event there is more than one equally low preferred bidder, the Director shall consider the preferred bidders as tie bidders and shall follow the process specified in Section 63G-6a-608 and Rule R23-1-10 .

 

R23-1-1002. Preference for Resident Contractors.

(1) In addition to the reciprocal preference requirements contained in Section 63G-6a-1003 for resident Utah contractors, this rule outlines the process for award of a contract when there is more than one equally low preferred resident contractor.

(2) In the event there is more than one equally low preferred resident contractor, the Director shall consider the preferred resident contractors as tie bidders and shall follow the process specified in Section 63G-6a-608 and this R23-1-10.

 

R23-1-1003. Exception for Federally Funded Contracts.

This Rule R23-1-10 does not apply to the extent it might jeopardize the receipt of federal funds, conflicts with federal requirements relating to a procurement that involves the expenditure of federal assistance, federal contract funds, or federal financial participation funds.

 

R23-1-1101. Definitions.

(1) Whenever used in this Rule, the terms "bid", "bidder" and "bid security" apply to all procurements, including non-construction procurements, when the procurement documents, regardless of the procurement type, require securities and/or bonds.

(2) All definitions in the Utah Procurement Code shall apply to this Rule unless otherwise specified in this Rule. This administrative rule provides additional requirements and procedures and must be used in conjunction with the Procurement Code.

 

R23-1-1102. Bid Security Requirements for Projects.

(1) Application. The requirements for bid security and bonds under this Rule R23-1-11 shall apply as follows:(a) For the Division, the award of construction contracts where the face amount of the contract is $100,000 or more.

(b) For other state agencies that are required to use the same or similar documents as the Division for their construction contracts, the award of construction contracts where the face amount of the contract is $50,000 or more, unless the Division Director, in writing, approves a $100,000 or more requirement similarly to the Division, based on:

(i) The Division Director's finding that the agency has a selection process for such contracts that are under $100,000, that ensures a responsible, financially solvent contractor is selected; and

(ii) that the agency has the financial capability to absorb the potential responsibility that can occur due to the lack of the bid security and bonding requirements for the contract under $100,000.

(c) At any time the Division or any other state agency can require acceptable bid security as well as performance and payment bonds on contracts that are for amounts below the standard requirements set forth above in this Rule.

(2) Acceptable Bid Security. The term "bid" as used in this Rule R23-1-1102 shall also be deemed to apply to "offer."

(a) Invitations for Bids and Requests For Proposals shall require the submission of acceptable bid security in an amount equal to at least five percent of the bid, at the time the bid is submitted. If a contractor fails to accompany its bid with acceptable bid security, the bid shall be deemed nonresponsive, unless this failure is found to be nonsubstantial as hereinafter provided.

(b) If acceptable bid security is not furnished in accordance with Rule R23-1-907(3), the bid shall be rejected as nonresponsive, unless the failure to comply is determined by the Director to be nonsubstantial. Failure to submit an acceptable bid security may be deemed nonsubstantial if:

(i) the bid security is submitted on a form other than the Division's required bid bond form and the bid security meets all other requirements including being issued by a surety meeting the requirements of Subsection (5);

(ii) the contractor provides acceptable bid security by 5 p.m. of the next business day after notice is provided by the Division of the defective bid security; or

(iii) only one bid is received.

(3) Payment and Performance Bonds. Except as provided in this Rule R23-1-1102(1) above, payment and performance bonds in the amount of 100% of the contract price are required for all contracts in excess of $50,000. These bonds shall cover the procuring agencies and be delivered by the contractor to the Division at the same time the contract is executed. If a contractor fails to deliver the required bonds, the contractor's bid shall be found nonresponsive and its bid security shall be forfeited.

(4) Forms of Bonds. Bid Bonds, Payment Bonds and Performance Bonds must be from sureties meeting the requirements of Rule R23-1-1102(5) and must be on the exact bond forms most recently adopted by the Board and on file with the Division.

(5) Surety firm requirements. All surety firms must be authorized to do business in the State of Utah and be listed in the U.S. Department of the Treasury Circular 570, Companies Holding Certificates of Authority as Acceptable Securities on Federal Bonds and as Acceptable Reinsuring Companies for an amount not less than the amount of the bond to be issued. A co-surety may be utilized to satisfy this requirement.

(6) Waiver. The Director may waive any bonding requirements set forth in this Rule if the Director finds circumstances in which the Director considers any or all of the bonds to be unnecessary to protect the State. Any such waiver shall be stated in writing, explain the circumstances why the bond(s) is not necessary to protect the procurement unit, and the waiver shall be made part of the project file.

(7) The Director may require an acceptable bid security on projects that are for amounts less than the standard amount set forth in this Rule R23-1-1102.

 

R23-1-1201. Required Contract Clauses.

(1) The Division shall comply with Sections 63G-6a-1202 considering clauses for contracts. The Division will establish standard contract clauses to assist the Division and to help contractors and potential contractors to understand applicable requirements. These standard contract clauses may be modified as needed to meet the requirements of the particular project.

(2) The Division shall also comply with the requirements of Section 63G-6a-402(6) by requiring that for each contract and request for proposals, the inclusion of a clause that requires the Division, for the duration of the contract, to make available contact information of the winning contractor to the Department of Workforce Services in accordance with Section 35A-2-203. This requirement does not preclude a contractor from advertising job openings in other forums throughout the state.

(3) There shall be compliance with the federal contract prohibition provisions of the Sudan Accountability and Divestment Act of 2007 (Pub. L. No. 110-174) that prohibit contracting with a person doing business in Sudan.

(4) All definitions in the Utah Procurement Code shall apply to this Rule unless otherwise specified in this Rule. This administrative rule provides additional requirements and procedures and must be used in conjunction with the Procurement Code.

 

R23-1-1202. Establishment of Terms and Conditions.

The Division may use the Standard Terms and Conditions adopted by the Division of Purchasing and General Services for a particular procurement with modifications.

 

R23-1-1203. Contracts and Change Orders -- Contract Types.

The Division may use contract types to the extent authorized under Section 63G-6a-1205.

 

R23-1-1204. Prepayments.

Prepayments are subject to the restrictions contained in Section 63G-6a-1208.

 

R23-1-1205. Leases of Personal Property.

Leases of personal property are subject to the following:

(1) Leases shall be conducted in accordance with Division of Finance rules and Section 63G-6a-1209.

(2) A lease may be entered into provided the procurement unit complies with Section 63G-6a-1209 and:

(a) it is in the best interest of the procurement unit;

(b) all conditions for renewal and costs of termination are set forth in the lease; and

(c) the lease is not used to avoid a competitive procurement.

(3) Lease contracts shall be conducted with as much competition as practicable.

(4) Executive Branch Procurement Unit Leases with Purchase Option. A purchase option in a lease may be exercised if the lease containing the purchase option was awarded under an authorized procurement process. Before exercising this option, the Division shall:

(a) investigate alternative means of procuring comparable procurement items; and

(b) compare estimated costs and benefits associated with the alternative means and the exercise of the option, for example, the benefit of buying new state of the art data processing equipment compared to the estimated, initial savings associated with exercise of a purchase option.

 

R23-1-1206. Multi-Year Contracts.

The Division may issue multi-year contracts in accordance with Section 63G-6a-1204. Section 63G-6a-1204 does not apply to a contract for the design or construction of a facility, a road, a public transit project, or a contract for the financing of equipment.

 

R23-1-1207. Installment Payments.

Procurement units may make installment payments in accordance with Section 63G-6a-1208.

 

R23-1-1208. Change Orders.

The Division shall comply with Section 63G-6a-1207.

 

R23-1-1209. Requirements for Cost or Pricing Data.

(1) For contracts that expressly allow price adjustments, cost or pricing data shall be required in support of a proposal leading to the adjustment of any contract pricing.

(2) Cost or pricing data exceptions:

(a) need not be submitted when the terms of the contract state established market indices, catalog prices or other benchmarks are used as the basis for contract price adjustments or when prices are set by law or rule;

(b) if a contractor submits a price adjustment higher than established market indices, catalog prices or other benchmarks established in the contract, the Director may request additional cost or pricing data; or

(c) the Director may waive the requirement for cost or pricing data provided a written determination is made supporting the reasons for the waiver. A copy of the determination shall be kept in the contract file.

 

R23-1-1210. Defective Cost or Pricing Data.

(1) If defective cost or pricing data was used to adjust a contract price, the vendor and the Division may enter into discussions to negotiate a settlement.

(2) If a settlement cannot be negotiated, either party may seek relief as provided by applicable laws and rules.

 

R23-1-1211. Cost Analysis.

(1) Cost analysis includes the verification of cost data. Cost analysis may be used to evaluate:

(a) specific elements of costs;

(b) total cost of ownership and life-cycle cost;

(c) supplemental cost schedules;

(d) market basket cost of similar items;

(e) the necessity for certain costs;

(f) the reasonableness of allowances for contingencies;

(g) the basis used for allocation of indirect costs; and,

(h) the reasonableness of the total cost or price.

 

R23-1-1212. Audit.

The Division may, at reasonable times and places, audit or cause to be audited by an independent third party firm, by another procurement unit, or by an agent of the procurement unit, the books, records, and performance of a contractor, prospective contractor, subcontractor, or prospective subcontractor.

 

R23-1-1213. Retention of Books and Records.

Contractors shall maintain all records related to the contract. These records shall be maintained by the contractor for at least six years after the final payment, unless a longer period is required by law. All accounting for contracts and contract price adjustments, including allowable incurred costs, shall be conducted in accordance with generally accepted accounting principles for government.

 

R23-1-1214. Inspections.

Circumstances under which the Division may perform inspections include inspections of the contractor's manufacturing/production facility or place of business, or any location where the work is performed:

(1) whether the definition of "responsible," as defined in Section 63G-6a-103(40) and in the solicitation documents, has been met or are capable of being met; and

(2) if the contract is being performed in accordance with its terms.

 

R23-1-1215. Access to Contractor's Manufacturing/Production Facilities.

(1) The Division may enter a contractor's or subcontractor's manufacturing/production facility or place of business to:

(a) inspect procurement items for acceptance by the procurement unit pursuant to the terms of a contract;

(b) audit cost or pricing data or audit the books and records of any contractor or subcontractor pursuant to Utah Code or Administrative Rule; and

(c) investigate in connection with an action to debar or suspend a person from consideration for award of contracts.

 

R23-1-1216. Inspection of Supplies and Services.

(1) Contracts may provide that the Director or Division may inspect procurement items at the contractor's or subcontractor's facility and perform tests to determine whether the procurement items conform to solicitation and contract requirements.

 

R23-1-1217. Conduct of Inspections.

(1) No inspector may change any provision of the specifications or the contract without written authorization of the Director. The presence or absence of an inspector or an inspection, shall not relieve the contractor or subcontractor from any requirements of the contract.

(2) When an inspection is made, the contractor or subcontractor shall provide without charge all reasonable facilities and assistance for the safety and convenience of the person performing the inspection or testing.

 

R23-1-1301. Purpose.

The purpose of this rule is to comply with the provisions of Sections 63G-6a-1302 and 1303 of the Utah Procurement Code. All definitions in the Utah Procurement Code shall apply to this Rule unless otherwise specified in this Rule. This administrative rule provides additional requirements and procedures and must be used in conjunction with the Utah Procurement Code.

 

R23-1-1302. Construction Management Rule.

As required by Section 63G-6a-1302, this rule contains provisions applicable to:

(1) selecting the appropriate method of management for construction contracts;

(2) documenting the selection of a particular method of construction contract management; and

(3) the selection of a construction manager/general contractor.

 

R23-1-1303. Application.

The provisions of Rules R23-1-1302 through R23-1-1306 shall apply to all procurements of construction.

 

R23-1-1304. Methods of Construction Contract Management.

(1) This Rule contains provisions applicable to the selection of the appropriate type of construction contract management.

(2) It is intended that the Director have sufficient flexibility in formulating the construction contract management method for a particular project to fulfill the needs of the procurement unit. The methods for achieving the purposes set forth in this rule are not to be construed as an exclusive list.

(3) Before choosing the construction contracting method to use, a careful assessment must be made by the Director of requirements the project shall consider, at a minimum, the following factors:

(a) when the project must be ready to be occupied;

(b) the type of project, for example, housing, offices, labs, heavy or specialized construction;

(c) the extent to which the requirements of the procurement unit and the way in which they are to be met are known;

(d) the location of the project;

(e) the size, scope, complexity, and economics of the project;

(f) the amount and type of financing available for the project, including whether the budget is fixed or what the source of funding is, for example, general or special appropriation, federal assistance moneys, general obligation bonds or revenue bonds, lapsing/nonlapsing status and legislative intent language;

(g) the availability, qualification, and experience of the procurement unit's personnel to be assigned to the project and how much time the procurement unit's personnel can devote to the project;

(h) the availability, qualifications and experience of outside consultants and contractors to complete the project under the various methods being considered;

(i) the results achieved on similar projects in the past and the methods used; and

(j) the comparative advantages and disadvantages of the construction contracting method and how they might be adapted or combined to fulfill the needs of the procuring agencies.

(5) The following descriptions are provided for the more common construction contracting management methods which may be used by the procurement unit. The methods described are not all mutually exclusive and may be combined on a project. These descriptions are not intended to be fixed in respect to all construction projects. In each project, these descriptions may be adapted to fit the circumstances of that project.

(a) Single Prime (General) Contractor. The single prime contractor method is typified by one business, acting as a general contractor, contracting with the procurement unit to timely complete an entire construction project in accordance with drawings and specifications provided by the procurement unit. Generally the drawings and specifications are prepared by an architectural or engineering firm under contract with the procurement unit. Further, while the general contractor may take responsibility for successful completion of the project, much of the work may be performed by specialty contractors with whom the prime contractor has entered into subcontracts.

(b) Design-Build. In a design-build project, an entity, often a team of a general contractor and a designer, contract directly with a procurement unit to meet the procurement unit's requirements as described in a set of performance specifications and/or a program. Design responsibility and construction responsibility both rest with the design-build contractor. This method can include instances where the design-build contractor supplies the site as part of the package.

(c) Construction Manager/General Contractor (Construction Manager at Risk). The Division may contract with the construction manager early in a project to assist in the development of a cost effective design. In a Construction Manager/General Contractor (CM/GC) method, the CM/GC becomes the general contractor and is at risk for all the responsibilities of a general contractor for the project, including meeting the specifications, complying with applicable laws, rules and regulations, that the project will be completed on time and will not exceed a specified maximum price.

 

R23-1-1305. Selection of Construction Method Documentation.

The Director shall include in the contract file a written statement describing the facts that led to the selection of a particular method of construction contract management for each project.

 

R23-1-1306. Special Provisions Regarding Construction Manager/General Contractor.

(1) In the selection of a construction manager/general contractor, a standard procurement process as defined in Section 63G-6a-103 may be used or an exception allowed under Part 8 of the Utah Procurement Code.

(2) When the CM/GC enters into any subcontract that was not specifically included in the construction manager/general contractor's cost proposal, the CM/GC shall procure the subcontractor(s) by using a standard procurement process as defined in Section 63G-6a-103 of the Utah Procurement Code or an exception to the requirement to use a standard procurement process, described in Part 8 of the Utah Procurement Code.

 

R23-1-1307. Special Provisions Regarding Design-Build.

(1) The Board authorizes the Division for State building construction projects to use a design-build provider as one method of construction contracting management.

(2) A design-build contract may include a provision for obtaining the site for the construction project.

(3) A design-build contract or a construction manager/general contractor contract may include provision by the contractor of operations, maintenance, or financing.

 

R23-1-1308. Drug and Alcohol Testing Required for State Contracts: Definitions.

The rules applicable to the Division for drug and alcohol testing are in Rule 23-7 of the Utah Administrative Code.

 

R23-1-1401. Procurement of Design-Build Transportation Project Contracts.

The Board recognizes that the Utah Department of Transportation is the rulemaking authority for rules under Section 63G-6a-1402(3)(a)(ii) governing the procurement of design-build transportation projects.

 

R23-1-1501. Architect-Engineer Procurement Process, General Process.

(1) Application. The provisions of Part 15 of the Utah Procurement Code apply to every procurement of services within the scope of the practice of architecture as defined by Section 58-3a-102, or professional engineering as defined in Section 58-22-102, except as authorized by Rule R33-4-105. All definitions in the Utah Procurement Code shall apply to this Rule unless otherwise specified in this Rule. This administrative rule provides additional requirements and procedures and must be used in conjunction with the Procurement Code.

(2) Architect-Engineer Evaluation Committee. The Director shall designate members of the Architect-Engineer Evaluation Committee. The evaluation committee must consist of at least three members who are qualified under Section 63G-6a-707.

(3) Request for Statement of Qualifications. The Division shall issue a public notice for a request for statement of qualifications to rank architects or engineers. The Division shall:

(a) state in the request for statement of qualifications:

(i) the type of procurement item to which the request for statement of qualifications relates;

(ii) the scope of work to be performed;

(iii) the instructions and the deadline for providing information in response to the request for statement of qualifications;

(iv) criteria used to evaluate statements of qualifications including:

(A) basic information about the person or firm;

(B) experience and work history;

(C) management and staff;

(D) qualifications and certification;

(E) licenses and certifications;

(F) applicable performance ratings;

(G) financial statements; and

(H) other pertinent information.

(b) Key personal identified in the statement of qualifications may not be changed without the advance written approval of the procurement unit.

(4) Not include Cost in Response. Architects and engineers shall not include cost in a response to a request for statement of qualifications.

(5) Evaluation of Statement of Qualifications. The evaluation committee shall evaluate statements of qualifications in accordance with Section 63G-6a-707 to rank (score) architects or engineers without considering cost.

(6) Negotiation and Award of Contract. The Director shall negotiate a contract with the most qualified firm for the required services at compensation determined to be fair and reasonable based on the Division's rate table or as may be reasonably adjusted by the Director for the particular scope of work, location or other aspects of the services.

(7) Failure to Negotiate Contract With the Highest Ranked Firm.

(a) If fair and reasonable compensation, contract requirements, and contract documents cannot be agreed upon with the highest ranked firm, the Director shall advise the firm in writing of the termination of negotiations.

(b) Upon failure to negotiate a contract with the highest ranked firm, the Director shall proceed in accordance with Section 63G-6a-1505 of the Utah Procurement Code.

(8) Notice of Award.

(a) The Director shall award a contract to the highest ranked firm with which the fee negotiation was successful.

(b) Notice of the award shall be made available to the public.

(8) Written Justification Statements. The Division shall issue a statement justifying the ranking of the firm with which fee negotiation was successful.

 

R23-1-1502. Disclosure of Submittals, Performance Evaluations, and References.

(1) Except as provided in this rule, submittals shall be open to public inspection after notice of the selection results.

(2) The classification of records as protected and the treatment of such records shall be as provided in Rule R23-1-705.

(3) The Board finds that it is necessary to maintain the confidentiality of performance evaluations and reference information in order to avoid competitive injury and to encourage those persons providing the information to respond in an open and honest manner without fear of retribution. Accordingly, records containing performance evaluations and reference information are classified as protected records under the provisions of Subsection 63G-2-305(6) and shall be disclosed only to those persons involved with the performance evaluation, the architect or engineer that the information addresses and persons involved with the review and selection of submittals. The Division may, however, provide reference information to other governmental entities for use in their procurement activities and to other parties when requested by the architect or engineer that is the subject of the information. Any other disclosure of such performance evaluations and reference information shall only be as required by applicable law.

 

R23-1-1503. Publicizing Selections.

(1) Notice. After the selection of the successful firm, notice of the selection shall be available in the principal office of the Division in Salt Lake City, Utah and may be available on the Internet

(2) Information Disclosed. The following shall be disclosed with the notice of selection

(a) the ranking of the firms

(b) the names of the selection committee members;

(c) the final scores used by the selection committee to make the selection, except that the names of the individual scorers shall not be associated with their individual scores; an

(d) the written justification statement supporting the selection.

(3) Information Classified as Protected. After due consideration and public input, the following has been determined by the Board to impair governmental procurement proceedings or give an unfair advantage to any person proposing to enter into a contract with the Division and shall be classified as protected records:

(a) the names of individual selection committee scorers in relation to their individual scores or rankings; and

(b) non-public financial statements.

 

R23-1-1504. Performance Evaluation.

(1) The Division shall evaluate the performance of the architectural or engineering firm and shall provide an opportunity for the using agency to comment on the Division's evaluation.

(2) This evaluation shall become a part of the record of that architectural or engineering firm within the Division. The architectural or engineering firm shall be provided a copy of its evaluation at the end of the project and may enter its response in the file.

(3) Confidentiality of the evaluation information shall be addressed as provided in Subsection R23-2-11(3).

 

R23-1-1601. Conduct.

Controversies and protests shall be conducted in accordance with the requirements set forth in Sections 63G-6a-1601 through 13G-6a-604. All definitions in the Utah Procurement Code shall apply to this Rule unless otherwise specified in this Rule. This administrative rule provides additional requirements and procedures and must be used in conjunction with the Procurement Code.

 

R23-1-1602. Verification of Legal Authority.

A person filing a protest may be asked to verify that the person has legal authority to file a protest on behalf of the public or private corporation, governmental entity, sole proprietorship, partnership, or unincorporated association.

 

R23-1-1603. Intervention in a Protest.

(1) Application. This Rule contains provisions applicable to intervention in a protest, including who may intervene and the time and manner of intervention.

(2) Period of Time to File. After a timely protest is filed in accordance with the Utah Procurement Code, the Protest Officer shall notify awardees of the subject procurement and may notify others of the protest. A Motion to Intervene must be filed with the Protest Officer no later than ten days from the date such notice is sent by the Protest Officer. Only those Motions to Intervene made within the time prescribed in this Rule will be considered timely. The entity or entities who conducted the procurement and those who are the intended beneficiaries of the procurement are automatically considered a Party of Record and need not file any Motion to Intervene.

(3) Contents of a Motion to Intervene. A copy of the Motion to Intervene shall also be mailed or emailed to the person protesting the procurement.

(4) Any Motion to Intervene must state, to the extent known, the position taken by the person seeking intervention and the basis in fact and law for that position. A motion to intervene must also state the person's interest in sufficient factual detail to demonstrate that:

(a) the person seeking to intervene has a right to participate which is expressly conferred by statute or by Commission rule, order, or other action;

(b) the person seeking to intervene has or represents an interest which may be directly affected by the outcome of the proceeding, including any interest as a:

(i) consumer;

(ii) customer;

(iii) competitor;

(iv) security holder of a party; or

(v) the person's participation is in the public interest.

(5) Granting of Status. If no written objection to the timely Motion to Intervene is filed with the Protest Officer within seven calendar days after the Motion to Intervene is received by the protesting person, the person seeking intervention becomes a party at the end of this seven day period. If an objection is timely filed, the person seeking intervention becomes a party only when the motion is expressly granted by the Protest Officer based on a determination that a reason for intervention exists as stated in this Rule. Notwithstanding any provision of this Rule, an awardee of the procurement that is the subject of a protest will not be denied their Motion to Intervene, regardless of its content, unless it is not timely filed with the Protest Officer.

(6) Late Motions. If a motion to intervene is not timely filed, the motion shall be denied by the Protest Officer.

 

R23-1-1701. Statutory and Rule Requirements.

Appeals to a protest decision shall be conducted in accordance with the requirements set forth in Section 63G-6a-1701 through 63G-6a-1706, Utah Procurement Code. Utah Administrative Code Rules R33-17-101 through R33-17-105 shall also apply.

 

R23-1-1801. Process.

(1) A person who receives an adverse decision, or a procurement unit (the Division), may appeal a decision of a procurement appeals panel to the Utah Court of Appeals within seven days after the day on which the decision is issued.

(2) All appeals to the Utah Court of Appeals are subject to the provisions of the requirements set forth in Section 63G-6a-1801 through 63G-6a-1803.

(3) The Division may only appeal a procurement appeals panel decision in accordance with Section 63G-6a-1802(2).

 

R23-1-1901. Encouraged to Obtain Legal Advice From Legal Counsel.

(1) All definitions in the Utah Procurement Code shall apply to this Rule unless otherwise specified in this Rule. This administrative rule provides additional requirements and procedures and must be used in conjunction with the Procurement Code.

(2) Part 19 of the Utah Procurement Code, Sections 63G-6a-901 through 63G-6a-1911 contain provisions regarding:

(a) limitations on challenges of:

(i) a procurement;

(ii) a procurement process;

(iii) the award of a contract relating to a procurement;

(iv) a debarment; or

(v) a suspension; and

(b) the effect of a timely protest or appeal;

(c) the costs to or against a protester;

(d) the effect of prior determinations by employees, agents, or other persons appointed by the procurement unit;

(e) the effect of a violation found after award of a contract;

(f) the effect of a violation found prior to the award of a contract;

(g) interest rates; and

(h) a listing of determinations that are final and conclusive unless they are arbitrary and capricious or clearly erroneous.

(3) Due to the complex nature of protests and appeals, any person involved in the procurement process, protest or appeal, is encouraged to seek advice from the person's own legal counsel.

 

R23-1-2001. General Provisions Related to Records.

General provisions related to records are in Part 20 of the Utah Procurement Code and in Rule R23-1-12.

 

R23-1-2101. Cooperative Purchasing.

Cooperative purchasing shall be conducted in accordance with the requirements set forth in Section 63G-6a-2105 and the Utah Administrative Code Rule R23-1. This Rule provides additional requirements and procedures and must be used in conjunction with the Utah Procurement Code.

 

R23-1-2102. State Cooperative Contracts.

(1) The Division shall obtain procurement items from state cooperative contracts whether statewide or regional unless the chief procurement officer determines, in accordance with Section 63G-6a-408(5)(b)(i), that it is in the best interest of the state to obtain an individual procurement item outside the state contract.

(2) In accordance with Section 63G-6a-2105, the Division, public entities, nonprofit organizations, and agencies of the federal government may obtain procurement items from state cooperative contracts awarded by the chief procurement officer.

 

R23-1-2201. Reserved.

Part 22 of Title 63G, Chapter 6a, the Utah Procurement Code, does not exist at this point in time. Rules R23-1-1 through R23-1-24 are designed to match the corresponding Part of the Utah Procurement Code. When Part 22 of the Utah Procurement Code contains statutory language, the Board will consider whether to prepare draft rules for the rulemaking process.

 

R23-1-2301. Reserved.

Part 23 of Title 63G, Chapter 6a, the Utah Procurement Code, does not exist at this point in time. Rules R23-1-1 through R23-1-24 are designed to match the corresponding Part of the Utah Procurement Code. When Part 23 of the Utah Procurement Code contains statutory language, the Board will consider whether to prepare draft rules for the rulemaking process.

 

R23-1-2401. Unlawful Conduct.

Unlawful conduct shall be governed in accordance with the requirements set forth in Sections 63G-6a-2401 through 2407. All definitions in the Utah Procurement Code shall apply to this Rule unless otherwise specified in this Rule. This administrative rule provides additional requirements and procedures and must be used in conjunction with the Procurement Code.

 

R23-1-2402. Laws and Executive Orders Pertaining to Gifts, Meals, and Gratuities for Executive Branch Procurement Professionals.

(1) A Division employee classified as a "Procurement Professional" shall be governed by:

(a) Part 24 of the Utah Procurement Code, "Unlawful Conduct and Penalties."

(b) Executive Order EO/003/2010 issued by the Governor (https://rules.utah.gov/execdocs/2010/ExecDoc149415.htm);

(c) Title 67, Part 16 "Utah Public Officers' and Employees' Ethics Act;"

(d) Section 76-8-103, "Bribery or Offering a Bribe;" and

(e) any other applicable law.

 

R23-1-2403. Laws and Executive Orders Pertaining to Gifts, Meals, and Gratuities for Executive Branch Employees.

(1) A Division employee not classified as a "Procurement Professional" shall be governed by:

(a) Executive Order EO/003/2010 issued by the Governor (https://rules.utah.gov/execdocs/2010/ExecDoc149415.htm);

(c) Title 67, Part 16 "Utah Public Officers' and Employees' Ethics Act;"

(d) Section 76-8-103, "Bribery or Offering a Bribe;" and

(e) any other applicable law.

 

R23-1-2404. Socialization with Vendors and Contractors.

(1) A procurement professional shall not:

(a) participate in social activities with vendors or contractors that will interfere with the proper performance of the procurement professional's duties;

(b) participate in social activities with vendors or contractors that will lead to unreasonably frequent disqualification of the procurement professional from the procurement process; or

(c) participate in social activities with vendors or contractors that would appear to a reasonable person to undermine the procurement professional's independence, integrity, or impartiality.

(2) If an executive branch procurement professional participates in a social activity prohibited under R23-1-2404(1), or has a close personal relationship with a vendor or contractor, the procurement professional shall promptly notify their supervisor and the supervisor shall take the appropriate action, which may include removal of the procurement professional from the procurement or contract administration process that is affected.

 

R23-1-2405. Financial Conflict of Interests Prohibited.

(1) A procurement conflict of interest is a situation in which the potential exists for an executive branch employee's personal financial interests, or for the personal financial interests of a family member, to influence, or have the appearance of influencing, the employee's judgment in the execution of the employee's duties and responsibilities when conducting a procurement or administering a contract.

(2) In order to preserve the integrity of the State's procurement process, an executive branch employee may not take part in any procurement process, contracting or contract administration decision:

(a) relating to the employee or a family member of the employee; or

(b) relating to any entity in which the employee or a family member of the employee is an officer, director or partner, or in which the employee or a family member of the employee owns or controls 10% or more of the stock of such entity or holds or directly or indirectly controls an ownership interest of 10% or more in such entity.

(3) If a procurement process, contracting or contract administration matter arises relating to the employee or a family member of the employee, the employee must advise his or her supervisor of the relationship, and must be recused from any and all discussions or decisions relating to the procurement, contracting or administration matter. The employee must also comply with all disclosure requirements in Utah Code Title 67 Chapter 16, Utah Public Offers' and Employees' Ethics Act.

 

R23-1-2406. Bias Participation Prohibitions.

(1) Division employees are prohibited from participating in any and all discussions or decisions relating to the procurement, contracting or administration process if they have a bias that would appear to a reasonable person to influence their independence in performing their assigned duties and responsibilities relating to the procurement process, contracting or contract administration or prevent them from fairly and objectively evaluating a proposal in response to a bid, RFP or other solicitation. This provision shall not be construed to prevent an employee from having a bias based on the employee's review of a response to the solicitation in regard to the criteria in the solicitation.

(2) If an executive branch employee has an impermissible bias under Rule R23-1-2406(1) above regarding an individual, group, organization, or vendor responding to a bid, RFP or other solicitation, the employee must make a written disclosure to the supervisor and the supervisor shall take appropriate action, which may include recusing the employee from any and all discussions or decisions relating to the solicitation, contracting or administration matter in question. This provision shall not be construed to prevent an employee from having a bias based on the employee's review of a response to the solicitation in regard to the criteria in the solicitation.

 

R23-1-2407. Professional Relationships and Social Acquaintances Not Prohibited.

(1) It is not a violation for an executive branch employee who participates in discussions or decisions relating to the procurement, contracting or administration process to have a professional relationship or social acquaintance with a person, contractor or vendor responding to a solicitation, or that is under contract with the State, provided that there is compliance with Rule R33-24-105, Rule R33-24-106, the Utah Public Officers' and Employees' Ethics Act, The Governor's Executive Order (EO 002 2014) "Establishing an Ethics Policy for Executive Branch Agencies and Employees," and other applicable State laws.

 

KEY: contracts, procurement,[architects, engineers, ]public buildings

Date of Enactment or Last Substantive Amendment: [August 7, 2012]2015

Notice of Continuation: December 18, 2014

Authorizing, and Implemented or Interpreted Law: [63G-6-101 et seq.]63A-5-103 et seq.; 63G-2-101 et seq.; 63G-6-208(2)

 


Additional Information

More information about a Notice of Proposed Rule is available online.

The Portable Document Format (PDF) version of the Bulletin is the official version. The PDF version of this issue is available at https://rules.utah.gov/publicat/bull-pdf/2015/b20150115.pdf. The HTML edition of the Bulletin is a convenience copy. Any discrepancy between the PDF version and HTML version is resolved in favor of the PDF version.

Text to be deleted is struck through and surrounded by brackets ([example]). Text to be added is underlined (example).  Older browsers may not depict some or any of these attributes on the screen or when the document is printed.

For questions regarding the content or application of this rule, please contact Alan Bachman at the above address, by phone at 801-538-3105, by FAX at 801-538-3313, or by Internet E-mail at abachman@utah.gov; Cecilia Niederhauser at the above address, by phone at 801-538-3261, by FAX at 801-538-9694, or by Internet E-mail at cniederhauser@utah.gov; Nicole Alder at the above address, by phone at 801-538-3240, by FAX at , or by Internet E-mail at nicolealder@utah.gov.  For questions about the rulemaking process, please contact the Division of Administrative Rules.